Case BriefsHigh Courts

Chhattisgarh High Court: Sanjay S. Agrawal, J., reversed the judgment of the trial court and granted divorce in an application filed by the husband, while granting Rs 15 lakhs permanent alimony to the wife.

Applicant-Husband had preferred an appeal under Section 28 of the Hindu Marriage Act, 1955 questioning the legality and propriety of the trial Court’s decision whereby the application seeking a decree for dissolution of marriage on the ground of desertion and cruelty was dismissed.

Questions for determination:

(i) Whether the Non-applicant – wife has deserted her husband since 12.08.2009 without any rhyme and reasons being assigned entitling the Applicant for the decree of dissolution of marriage on the ground of desertion under Section 13 (1) (ib) of the Act, 1955?

(ii) Whether the Non-Applicant – Wife has levelled the false allegations against her husband pertaining to the demand of dowry by lodging a false complaint under Section 498-A of IPC read with Section 4 of Dowry Prohibition Act entitling the Applicant for the decree of dissolution of marriage on the ground enumerated under Section 13 (1) (ia) of the Act, 1955?

Analysis and Decision

High Court on noting that the applicant was living with another woman, therefore, there was a reason as to why the non-applicant had started living separately from her husband.

Therefore, the husband failed to establish the fact that his wife had deserted him without any justifiable reasons so as to obtain a decree for dissolution of marriage on the ground of desertion under Section 13(1) (ib) of the Act, 1955.

Further, on close scrutiny of the wife’s statement, it was revealed that the wife was never subjected to cruelty with regard to the demand of dowry as no evidence was led by her in this regard. Hence, the alleged complaint by the non-applicant was false.

Court added that the alleged marriage of the husband and wife had irretrievably broken down and was dead for all purposes.

The husband and wife were not only living separately for over more than 11 years, but a false criminal case was also found to be lodged by the non-applicant-wife against her husband, which caused mental cruelty to him.

Therefore, the husband would be entitled to get a decree for dissolution of marriage on the ground enumerated under Section 13 (1) (ia) of the Act, 1955 and, the finding of the trial Court declining to grant a decree for divorce on the ground of cruelty was accordingly set aside and the applicant was held to be entitled to a decree for divorce under Section 13 (1) (ia) of the Act, 1955.

With regard to the alimony, Court stated that, by considering the conditions prescribed under Section 25 of the Act, 1955 relating to claim of permanent alimony/maintenance and considering further the fact that the Non-applicant – wife has no independent source of income and that by taking note of the income of the Applicant – husband as reflected and observed from the details furnished coupled with the period of marriage, the ends of justice would be served by fixing amount of permanent alimony/maintenance at Rs 15,00,000 in lump sum payable to the non-applicant wife.

In the above direction, Court added that the applicant shall be entitled to deduct the maintenance amount from the permanent alimony.

In view of the above, the appeal was allowed. [Vasudev Prajapati v. Sunita Kumari, FA (M) No. 9 of 2015, decided on 28-4-2022]


Advocates before the Court:

For Appellant: Shri Manoj Paranjpe appears along with Shri Anurag Singh and Shri Subhank Tiwari, Advocate.

For Respondent: Shri H.B. Agrawal, Sr. Advocate along with Shri Amit Tirkey, Advocate.

High Court Round UpLegal RoundUp

110 Reports from 20 High Courts


Allahabad High Court


  • Money Laundering

For money launderers “jail is the rule and bail is an exception”

While addressing a matter with regard to anticipatory bail, Krishan Pahal, J., observed that, Money Laundering being an offence is economic threat to national interest and is committed by the white-collar offenders who are deeply rooted in society and cannot be traced out easily.

Read full report here…

  • Right to Approach the Court

Person whose case is based on falsehood has no right to approach the Court

Expressing that Courts of law are meant for imparting justice, Sanjay Kumar Singh, J., observed that more often the process of Court is being abused by unscrupulous litigants to achieve their nefarious design.

Read full report here…

  • Bail

Cogent and clinching evidence found regarding conversion of deaf and dumb students to Islam; Bail denied

The Division Bench of Brij Raj Singh and Ramesh Sinha, JJ. dismissed a criminal appeal which was filed under Section 21 (4) of the National Investigation Agency Act, 2008 of refusal of bail to the appellant.

Read full report here…

Unity of India is not made of bamboo reeds which will bend to the passing winds of empty slogans; foundations of our nation are more enduring: All HC while granting bail to Kashmiri Students

Expressing that Students travelling freely to different parts of the country in the quest for knowledge is the true celebration of India diversity and a vivid manifestation of India’s unity, Ajay Bhanot, J., stated that it is the duty of the people of the hosting State to create enabling conditions for visiting scholars to learn and to live the constitutional values of our nation.

Read full report here….


Andhra Pradesh High Court


  • Arms Act

Will carrying of toy gun in public attract S. 25 of Arms Act? Bail granted to a man giving stills as a hero with an air gun in a cinema theatre

“…the offences punishable under Sections 290, 506(2) IPC are bailable in nature. As regards the offence punishable under Section 25 of the Arms Act, 1959, is concerned, the pistol which was seized from the possession of A-1 is an air gun. It is a toy gun.”

Read full report here…

  • Wilful Negligence

No offence made out under POA Act against bank officials who misplaced the house documents and title deeds of a claimant as FIR does not show wilful Negligence by a public servant

The Court after perusing Section 3(1) (v) and 3(2) (vii) and Section 4 of POA, Act, which deals with punishment for neglect of duties it is clear that these cannot be made applicable to the facts in issue. Section 3(2)(vii) postulates a situation where a person being a public servant commits any offence under this section i.e., Section 3(2) shall be punishable with imprisonment for a term which shall be less than one year but which may extend to the punishment provided for that offence. 

Read full report here…

  • Vakalat and Written

Signatures on the Vakalat and the Written Statement cannot be considered as signatures of comparable and assured standard for want of expert opinion under S. 45 Evidence Act

Ninala Surya, J., decided to not interfere with the impugned order and dismissed the civil writ petition.

Read full report here…


Bombay High Court


  • Child Marriages

Child marriages will have to be stopped and no person can be allowed to take advantage of any such situation

Vibha Kankanwadi, J., expressed that Child marriages are hazardous to the social fabric of this Country.

Read full report here…

  • Decorum of Court

Advocate to maintain dignity & decorum of Court, no room for arrogance and no license to intimidate Court

Anuja Prabhudessai, J., expressed that an advocate as an Officer of the Court is under an obligation to maintain the dignity and decorum of the Court. There is no room for arrogance and there is no license to intimidate the Court, make reckless accusations and allegations against a Judge and pollute the very fountain of justice.

Read full report here…

  • Compassionate Appointment

Can legal heir of deceased employee be granted compassionate appointment, who took voluntary retirement due to being medically unfit?

Ravindra V. Ghuge, J., decides a matter as to whether the benefit of compassionate appointment can be granted to the legal heir of the employee, who took voluntary retirement and was never certified as being medically unfit to perform any work, though the reason for opting for retirement was a serious medical condition.

Read full report here…

  • Religious Verses

Declaration of reciting religious verses at someone’s residence: Act of breaching personal liberty of another person?

Stating that, “Great power comes with greater responsibility”, the Division Bench of Prasanna B. Varale and S.M. Modak, JJ., expressed that, the expectation of responsible behaviour or responsible conduct from those persons who are active in public life cannot be an extra expectation but would be a basic expectation.

Read full report here…

  • Eviction

Son not expected to brand his aged father a ‘swindler’ or allege that aged parents have lost mental balance

In a matter wherein, the parents sought eviction of their sonRohit B. Deo, J., expressed that,

“In the conservative Indian society, a son is not expected to brand his aged father a ‘swindler’ or then allege that the aged parents have lost mental balance.”

Read full report here…

  • Arbitration and Conciliation Act

Can mere filing of proceedings under S. 7 IBC be treated as an embargo on Court exercising jurisdiction under S. 11 of Arbitration & Conciliation Act?

A very interesting question was considered by G.S. Kulkarni, J., the question being, whether mere filing of a proceeding under Section 7 of the Insolvency and Bankruptcy Code, 2016 would amount to an embargo on the Court considering an application under Section 11 of the Arbitration and Conciliation Act, 1996, to appoint an arbitral tribunal?

Read full report here…

  • Land Acquisition

For determining land acquisition compensation, market value, if any, specified in Stamp Act for registration of Sale Deed and/or Agreement of Sale has to be considered

The Division Bench of S.V. Gangapurwala and Vinay Joshi, JJ., expressed that only because 83% of the property for the project is acquired, it would be egregious not to apply the provision of the statute for determination of compensation.

Read full report here…

  • Pension

If service of an employee at his superannuation is less than ten years, then previous temporary or officiating service needed to be counted for qualifying service for pension

The Division Bench of R.D. Dhanuka and S.G. Mehare, JJ., expressed that, for condoning the interruption in service, the total service pensionary benefit in respect of which will lost should not be less than five years duration, excluding one or two interruptions.

Read full report here…

  • Partition

In a suit for partition, the heads of all the branches are necessary parties

Mangesh S. Patil, J., decided on the following questions for consideration:

  • Whether in a suit for partition and possession of the field all the sharers and co-partners are necessary parties?
  • Whether suit for partition and possession is bad for non-joinder of necessary parties and therefore ought to have been dismissed?
  • Whether in the circumstances of the case, the observation regarding non-joinder of necessary parties, made by the appellate court, are proper?

Read full report here…

  • Maintenance

Can filing of a maintenance proceeding, a criminal case for harassment be said to be sufficient to jump to a conclusion that wife intended to harass husband and his relations?

In a matter of matrimonial discord, Mangesh S. Patil, J., expressed that, when admittedly, for whatever reason, there was a marital discord and the wife had started residing with the infant child at her parental house barely within three years of her marriage, it cannot be expected of her not to prosecute whatever rights and remedies she has under the law.

Read full report here…

  • “No Confidence”

If directly elected Sarpanch acts in a manner rendering functioning of Panchayat at a standstill, would member of panchayat get right to move motion of ‘no confidence’?

Stating that in the democratic setup, the will of the majority is the rule, the Division Bench of S.V. Gangapurwala and Shrikant D. Kulkarni, JJ., held that if the directly elected Sarpanch fails to call the meetings of the Panchayat or acts in a manner rendering the functioning of the Panchayat at a standstill, the member of the Panchayat would certainly get a right to move a motion of no confidence.

Read full report here…

  • Motor Accident Case

Determination of a just compensation cannot be equated to be a bonanza

Addressing a dispute with regard to the percentage of permanent disability and determination of compensation, Shrikant D. Kulkarni, J., remarked that determination of a just compensation cannot be equated to be a bonanza.

Read full report here…

  • Society

Can minority members of a Society act against will of majority members and foist delay in commencement of redevelopment work of Society?

Observing that, a developer who has been appointed by the Society and who is eager to proceed with the redevelopment, was in some manner left baffled and dragged into litigationG.S. Kulkarni, J., held that, non-cooperating members cannot foist a delay on the builder and the society in the commencement of the redevelopment work resulting in the project costs being increased every passing day.

Read full report here…

  • Abortion

Past pregnancy can be determined on account of permanent changes in the body of a woman

While addressing a matter, wherein the accused who was a doctor charged for raping a minor stated that there was not any proof that the girl ever conceived or had undergone any abortion, M.G. Sewlikar, J., expressed that, Medical science is so advanced that now a days past pregnancy also can be determined on the basis of changes in the body of a woman on account of pregnancy.

Read full report here…

  • Custody of Child

Non-custodial parent cannot be deprived of his right to spend quality time and enjoy company of children

Anuja Prabhudessai, J., expressed that the children also have the right to love and affection from both parents as well as grandparents as it is essential for the personal development and overall well-being of the children.

Read full report here…

  • Partnership Act

Every partner is liable, jointly with all other partners and also severally for all acts of firm done while he is a partner: Is it true?

Expressing that, a firm is not a legal entity, N.J. Jamadar, J., held that a partnership firm is only a collective or compendious name for all the partners.

Read full report here…

  • Constitutional Validity of S. 29A of Consumer Protection Act

Whether absence of President of State Commission or District Forum for reasons beyond control is sufficient for striking down S. 29A as unconstitutional?

Stating that, the Courts cannot examine the constitutional validity if a situation created by impugned legislation is irremediable, the Division Bench of V.M. Deshpande and Amit B. Borkar, JJ., addressed a matter wherein the constitutional validity of Section 29A of the Consumer Protection Act, 1986 has been challenged.

Read full report here…

  • Lawyer-Client Relationship

Lawyer-client relationship is a fiduciary one; any act which is detrimental to legal rights of clients’ needs to be punished

Stating that it is the duty of every Advocate to uphold professional integrity so that citizens can legally secure justicethe Division Bench of V.M. Deshpande and Amit B. Borkar, JJ., expressed that, professional misconduct refers to its disgraceful conduct not befitting the profession concerning the legal profession, which is not a business or trade and therefore, it must remain decontaminated.

Read full report here…

  • Sale Deed

Whether a natural guardian having executed sale-deed of property of a minor in favour of a third party and thereafter repurchased part of it, can be prosecuted for offences under Ss. 420, 467, 468, 471 of IPC that too, after more than 35 years from date of attaining majority by minor?

The Division Bench of V.M. Deshpande and Amit Borkar, JJ., expressed that a transaction by a natural guardian of a minor with respect to his immovable properties is valid till a Court strikes it down.

Read full report here…

  • Muslim Personal Law

Under Muslim Personal law, can Family Court dissolve the marriage of a couple?

The Division Bench of V.K. Jadhav and Sandipkumar C. More, JJ., addressed whether Family Court under Muslim Personal Law (Shariat) Application Act, 1937 read with Section 7(1)(b) Explanation (b) of the Family Courts Act, 1984 declare the matrimonial status of a wife and husband.

Read full report here…

  • Competition Commission of India

Competition Commission of India not to take any coercive actions against Asianet, Disney and Star India until 8th June

The Division Bench of G.S. Patel and Madhav J. Jamdar, JJ., directed the Competition Commission of India not to take any coercive actions against Asianet Star Communications Private Limited, Disney Broadcasting and Star India.

Read full report here…

  • Alimony

Whether the husband is entitled to claim alimony under Section 25 of the Hindu Marriage Act, 1955?

Bharati Dangre, J., held that provision of maintenance/permanent alimony being a beneficial provision for the indigent spouse, Section 25 can be invoked by either of the spouse, where a decree of any kind governed by Sections 9 to 13 has been passed and marriage tie is broken, disrupted or adversely affected by such decree of the court.

Read full report here…

  • Properties

Daughters and widow of a deceased would inherit properties of deceased as tenants in common or joint tenants?

Mangesh S. Patil, J., expressed that, by virtue of Section 19 of the Hindu Succession Act, it has been explicitly made clear that if two and more heirs succeed together to the property and in the estate, they take the property as tenants in common and not as joint tenants.

Read full report here…


Calcutta High Court


  • Departmental Proceedings

DGP directed to initiate departmental proceedings against Police Officers; CID to take over investigation

Rajasekhar Mantha, J. while adjudicating a case involving serious offences under Section 365, 354B and other provisions of IPC directed the Director General of Police, West Bengal to initiate appropriate departmental proceeding against the ASI, Arnab Chakraborty and any other person that he may feel was responsible for misleading the Court further handing over the investigation to CID, West Bengal.

Read full report here…

  • Policy Decisions

Policy decisions of State not to be disturbed unless found to be grossly arbitrary or irrational; prayer for extension of lease rejected

Shampa Sarkar, J. decided on a petition which was filed for a direction upon the respondents 7 and 8 to cancel and/or quash the notice dated April 6, 2022, with regard to handing over the possession of the ferry ghat to the Pradhan of the Mahanandatola Gram Panchayat, upon expiry of the lease of the petitioner.

Read full report here…

  • Currency Notes

There are many known heroes and unsung heroes, if everybody starts making such a claim there will not be an end; Petition for printing Netaji’s picture on currency notes dismissed

The Division Bench of Prakash Shrivastava, CJ. and Rajarshi Bharadwaj, J. dismissed a petition which was filed by the petitioner with the plea that having regard to the contribution of Netaji Subhas Chandra Bose in the freedom struggle, his picture should be printed on the Indian currency.

Read full report here…

  • Arbitration and Conciliation Act

Scope of S. 9 of A&C Act cannot be extended to enforcement of award or granting fruits of award to award holder as an interim measure; application dismissed

Ravi Krishan Kapur, J. dismissed an application which was filed under Section 9 of the Arbitration and Conciliation Act, 1996 (‘the Act’) wherein liberty to withdraw a sum of Rs 4,11,89,759/- deposited by the award debtor, State of West Bengal, with the Registrar, Original Side of this Court upon furnishing of appropriate security was sought.

Read full report here…

  • Rape

Lady IPS Officer directed to investigate in the recent matter of 4 rape cases in the villages

The Division Bench of Prakash Shrivastava, CJ. and Rajarshi Bharadwaj, J. took up a petition and directed Damayanti Sen, IPS presently working as Special Commissioner of Police to Kolkata Police to investigate in the matter of rape cases at village Nehalpur, Nandipara, incident on Dol Purnima and English Bazar.

Read full report here…

  • Indian Forest Act

Court orders release of vehicles confiscated under the Indian Forest Act with unprecedented observations

Rabindranath Samanta, J. allowed a criminal revision petition which was filed aggrieved by the order of Magistrate wherein he had rejected the prayers made by the petitioners for return of two vehicles which were seized by the Deputy Ranger (Beat Officer), Bamonpokhari Range Office of the Forest Range, Kurseong Forest Range, Darjeeling

Read full report here…

  • GST Act

The interest of revenue has been safeguarded; Order of detention against the State upheld in matter of GST Act

The Division Bench of T. S. Sivagnanam and Hiranmay Bhattacharyya, JJ., dismissed an appeal and connected application which was filed by the State against  the order of detention passed by the authority detaining two trucks containing consignment of steel and other products in WPA 17611 of 2021 dated: 07-12-2021 wherein petitioner was the wife of late Mohit Madhogoria, who was a registered dealer under the provisions of the W.B.V.A.T. Act presently under the GST Act.

Read full report here…


Chhattisgarh High Court


  • Legislation

Whenever substantive obligation/rights/ interests are impaired/adversely affected through any piece of subordinate legislation, then its source must be traced within express provisions in four corners of parent enactment

“…the very object and reason behind framing of the Pharmacy Act, 1948 was to ensure that only persons with a minimum standard of professional education should be permitted to practice the profession of pharmacy.”

Read full report here…

  • Unlawful Detention

Writ of habeas corpus is a writ of right, it is not a writ of course; a prima facie case of unlawful detention must be made

The writ of habeas corpus is an effective means of immediate release from the unlawful detention, whether in prison or in private custody. Physical confinement is not necessary to constitute detention. Control and custody are sufficient. For issuance of a writ of habeas corpus, the applicant must show a prima facie case of unlawful detention of the subject.

Read full report here…

  • Section 304 B of Penal Code, 1860

An order of acquittal is not to be set aside lightly; Chh HC observes in a case where daughter in law committed suicide in unnatural circumstances

The Court after perusing evidence and facts observed that the finding of the Trial Court that the prosecution has failed to prove that soon before the death of the deceased she was subjected to cruelty on account of demand of dowry is totally based on the evidence available on record.

Read full report here…

  • Will

Daughters also entitled for getting equal share in the property inherited by their parents; Court reiterates and allows appeal deciding validity of will

Narendra Kumar Vyas, J. allowed an appeal filed by the defendants setting aside the judgment and decree by the Trial Court whereby trial Court had decreed the suit filed by plaintiff/respondent 1, dismissed the counter claim filed by appellants/defendants 1 to 3.

Read full report here…

  • Criminal Trial

Criminal trial and confiscation proceedings may run simultaneously; Once the information of confiscation proceeding under S. 52 (e) Indian Forest Act is given to DM, Trial Magistrate has no power over it

“…a bare reading of Section 52, Indian Forest Act, 1927 makes it clear that Forest Officer has power to confiscate the vehicle and the Competent Authority after giving show cause notice to the petitioner.”

Read full report here…

  • Abduction

If a girl runs away voluntarily without any persuasion, can boy with whom she eloped be held responsible for abducting the girl?

Deepak Kumar Tiwari, J., held that, when the accused has not played any active role or persuaded the victim and the victim voluntarily left the protection of her parents and having capacity to know her action, no offence of abduction is made out.

Read full report here…


Delhi High Court


  • Maintenance

Husband with sufficient means, is obligated to maintain wife and children?

In a maintenance matter, Subramonium Prasad, J., expressed that, if a husband has sufficient means, he is obligated to maintain his wife and children and not shirk away from his moral and familial responsibilities

Read full report here…

  • Rule of Law

Whether absence of rule of law or utter disregard for the same propels a country towards inevitable ruin?

Expressing that, attempts to circumvent or undermine judicial decisions need to be viewed seriously in order to ensure that the functioning of our country is unhindered, especially during turbulent times, Subramonium Prasad, J., held that,

“It is only the rule of law which not only cements the civilised functioning of a country, but also drives a country towards progress and development.”

Read full report here…

  • Framing of Charge

Does framing of charge means that accused is guilty or does it imply that accused may be guilty?

“The beauty of procedural law lies in the stages and remedies available during the course of a criminal proceeding.”

Read full report here…

  • Levy of Liquidated Damages

 If a contract comprises, several components awarded to different contractors, would it be inapposite to blame contractor that was last in completing work for loss suffered on account of delay in completing Project?

While reiterating the law on award of liquidated damages, Vibhu Bakhru, J., expressed that, where a contract comprises, several components awarded to different contractors, it is inapposite to blame the contractor that is last in completing the work for loss suffered on account of delay in completing the Project.

Read full report here…

  • Arbitration Agreement

Rule of priority in favour of arbitrators is counterbalanced by Courts’ power to review existence and validity of arbitration agreement

“Once a valid arbitration agreement exists between the parties, the issue whether the petitioner is entitled to any relief in the absence of a third party to the agreement or that third party is required to be impleaded in the proceedings, is covered by the Doctrine of Competence-Competence and it will be for the Arbitrator to decide the said issue.”

Read full report here…

  • PC & PNDT Act

Can Court take cognizance of complaint filed by single-member Appropriate Authority for offences under PC&PNDT Act, 1994?

Mukta Gupta, J., held that, the Metropolitan Magistrate/ Judicial Magistrate of the first class is competent to take cognizance and try the offence punishable under the PC&PNDT Act on the complaint of an Appropriate Authority or any officer authorised on this behalf by the Central Government or the State Government or the Appropriate Authority under sub-Section (1) of Section 28 of the Pre-Conception and Pre Natal-Diagnostic Techniques (Prohibition of Sex Selection) Act, 1994.

Read full report here…

  • Jurisdiction

Can power under S. 482 CrPC be exercised where allegations are required to be proved in Court of law?

Rajnish Bhatnagar, J., expressed that the Court in the exercise of its jurisdiction under Section 482 CrPC cannot go into the truth or otherwise of the allegations made in the complaint or delve into the disputed question of facts.

Read full report here…

  • Recusal of Judge

When a Judge recuses without reasons, can a litigant or third party intervene, comment or enquire?

Asha Menon, J., held that, when a Judge recuses, no litigant or third party has any right to intervene, comment or enquire. The recusal has to be respected, whether a reason has been spelt out in detail or not.

Read full report…

  • Adultery

Only continuous and repeated acts of adultery and/or cohabitation in adultery would attract rigours of provision under S. 125(4) CrPC

While addressing a matter with regard to a wife’s right to maintenance Chandra Dhari Singh, J., expressed that, only continuous and repeated acts of adultery and/or cohabitation in adultery would attract the rigours of the provision under Section 125(4) CrPC.

Read full report here…

  • Civil Contempt

Disobedience of an order of Court, if permitted, will result in striking at root of rule of law

Whether the third party can be absolved from contempt if they are informed that their conduct would violate the Court order, Subramonium Prasad, J., reiterated the well-settled position that though broadly a person who is not a party to the proceedings cannot be proceeded against for violation of the order, but a third party cannot seek to absolve themselves if they are informed about the fact that their conduct amounts to a violation of the Court and that despite the information, they choose to willfully flout the mandate of the Court.

Read full report here…

  • Denial of Sex

Whether denial of sex can qualify as “exceptional depravity” under S. 14 of the Hindu Marriage Act and allow waiver of one-year mandatory period?

Noting that, Section 14 of the Hindu Marriage Act intends to discourage the couples from breaking the sacred bond of marriage in haste, the Division Bench of Vipin Sanghi, ACJ and Jasmeet Singh, J., held that, a mandatory one year period granted under Section 14 of the Act, encourages couples to cool down, and give a rethink to preserve their marriage.

Read full report here…

  • Bail

Person accused of defrauding Government: Will Del HC grant bail to the accused?

Prateek Jalan, J., grants bail to a person who was alleged to cause fraudulent transactions and loss to the government.

Read full report here…

Cocoon of protection, afforded by a bail order insulates suspect and he could thwart interrogation reducing it to futile rituals

Asha Menon, J., expressed that, personal liberty is a very precious fundamental right and it should be curtailed only when it becomes imperative according to the peculiar facts and circumstances of the case.

Read full report here…

  • Arbitration and Conciliation Act

Scope of examination under S. 11 of A&C Act is confined to existence of arbitration agreement or does it extend to adjudicating nature of contract as well?

Vibhu Bakhru, J., held that whether claims are barred by limitation is a mixed question of fact and law and is required to be examined by the Arbitral Tribunal.

Read full report here…

Whether an award passed under S. 34(4) of the A&C Act is a fresh award for the purpose of S. 34 of the Act?

Vibhu Bakhru, J., allowed an amendment application seeking amendment of a petition filed under Section 34 of the Arbitration and Conciliation Act.

Read full report here…

  • Infringement

Red Bull v. Sting | Injunction application against Pepsico’s tagline “STIMULATES MIND ENERGIZES BODY”: Whether Pepsi has committed infringement?

Amit Bansal, J., observed that the taglines of ‘Red Bull’ and ‘Sting’ are descriptive and laudatory in nature.

Read full report here…

  • Scholarship Advertisement

If an advertisement regarding scholarship was published in Urdu language, can it be presumed that it was targeted at students belonging to a particular community only?

The Division Bench of Manmohan and Dinesh Kumar Sharma, JJ., expressed that just because the scholarship advertisement was published in the Urdu language, does not mean that it was targeted at students belonging to a particular community only.

Read full report here…

  • COVID-19

Can Delhi High Court direct State for payment of ex gratia compensation of Rs 1 Crore to families whose members died due to COVID-19?

The Division Bench of Vipin Sanghi, ACJ and Navin Chawla, J., held that this Court cannot direct payment of ex gratia compensation of Rs 1 Crore to families whose members died due to COVID-19.

Read full report here…

  • Physical relations on Promise to Marry

 Long term relationship with intent of marriage ended on hostile terms, would it be covered under S. 376(2)(n) IPC?

Noting that the Trial Court failed to perform its duty and rendered a mechanical order, Subramonium Prasad, J., set aside the trial Court’s order in a matter wherein, a woman had alleged that she was subjected to physical relationship with a boy on a false promise of marriage.

Read full report here…

  • Political Clearance

Judges required to seek political clearance qua private visits abroad: Did Del HC strike down Ministry of External Affairs’ Office Memorandum requiring the same?

The Division Bench of Rajiv Shakdher and Jasmeet Singh, JJ., strikes down the OM dated 13-7-2021, to the extent it requires Judges of the Supreme Court and the High Court to seek political clearance qua private visits abroad.

Read full report here…

  • Natural Justice

Refusal of a trade mark without even affording a hearing would be contrary to fundamental tenets of natural justice

Prathiba M. Singh, J., expressed that, refusing trade mark without even affording a hearing would be contrary to the fundamental tenets of natural justice.

Read full report here…

  • LOC issued against Rana Ayyub

Infringement of Human Rights and restraint of her freedom of speech and expression?

While expressing that a LOC is a coercive measure to make a person surrenderChandra Dhari Singh, J., noting that the petitioner had appeared on each and every date before the Investigating Agency when summoned, quashed the LOC issued against Rana Ayyub.

Read full report here…

  • Arbitration and Conciliation Act

Vibhu Bakhru, J., forms an arbitration tribunal to adjudicate the matter with regard to use the brand name/trademark “Hero”.

Read full report here…

  • Custodial Interrogation

Father of deceased accuses brother-in-law for her suicide: If chargesheet has already been filed, is there any need of custodial interrogation?

Chandra Dhari Singh, J., decides a bail matter wherein a woman was alleged to have committed suicide due to harassment and dowry demands by in-laws.

Read full report here…


Gujarat High Court


  • Reinstatement of Employee

Court directs reinstatement of employee alleged of corruption charges; termination order quashed

Biren Vaishnav, J. allowed a petition which was filed challenging the order of termination passed by the respondent – authority, by which, the services as Assistant Motor Vehicle Inspector, Class-III of the petitioner has been terminated on the ground of lodging of an FIR under Sections 7, 8, 12, 13(1)(D) and 13(2) of the Prevention of Corruption Act.

Read full report here…

  • Bail

First step of turning him into a hardcore criminal will be sending him behind bars; Court allows bail

A.S. Supehia, J. allowed a bail application in connection with FIR filed for the offences under Sections 363, 366, 376(2)(n), 376(3) of the Penal Code, 1860 as well as Sections 4, 6, and 12 of the Protection of Children from Sexual Offences Act, 2012 (POCSO Act).

Read full report here…

  • Custody of Children

Mother alleged to have extra-marital affair, will father be granted custody of children?

Ashok Kumar C. Joshi, J., denied granting child custody to father, wherein the mother was alleged to have extra-marital affairs.

Read full report here…


Himachal Pradesh High Court


  • COVID-19

PIL filed by an advocate for grant of stipend to her as well other Advocates, who have not completed 3 years of practice on account of Covid-19; HP HC directs to approach State Bar

A Division Bench of Mohammad Rafiq CJ. and Jyotsna Rewal Dua JJ. disposed of the petition and directed to approach State Bar Council.

Read full report here…


Jharkhand High Court


  • Natural Justice

Principles of natural justice required to be followed and cannot be waived out depending upon quantum of punishment; Reiterated mandate of natural justice in blacklisting cases

The Court remarked that the cardinal principle of natural justice is mandatory to be followed in a case where any adverse decision/action is being taken against one or the other. The issuance of notice means that the person against whom any adverse action proposed to be taken, is required to be provided with the opportunity of hearing.

Read full report here…


Jammu and Kashmir and Ladakh High Court


Advocates are officers of Court and deserve same respect and dignity as is being given to Judicial and Presiding Officers of Courts

Sanjay Dhar, J., expressed that, there may be stray incidents where the advocates have resorted to levelling allegations against the Judicial Officers in order to seek transfer of their cases from one Court to another to suit their convenience, but then this cannot be generalized.

Read full report here…

  • Maintenance

Minor seeks maintenance but issue of her paternity is in question: Will J&K and Ladakh HC grant maintenance amidst the dispute?

“…grant of maintenance to a minor child should be the paramount consideration for a Magistrate dealing with a petition under Section 125 CrPC, but when the paternity of a child is seriously disputed and there is no prima facie material to suggest that the respondent happens to be the father of the child, it would not be prudent for a Magistrate to fasten the respondent with the liability of maintaining the child.”

Read full report here…


Kerala High Court


  • Sexual Assault

In the guise of applying makeup, a bridal make up artist alleged sexually assaulted several women: Can he be granted anticipatory bail?

Gopinath P., J., granted bail to the bridal make up artist who was alleged to have sexually assaulted several women in the guise of applying make up.

Read full report here…

  • Media Trial

Can media be given right to speculate on outcome of one going investigations or Court proceedings or criminal trials?

While addressing the matter with regard to the media trial, Mohammed Nias C.P., J., expressed that, half-truths and misinformation cannot be the basis of publications or telecast.

Read full report here…

  • Alimony

Can children claim any amount under the head of permanent alimony under S. 25 of the Hindu Marriage Act?

Observing that trauma in a marital discord is common to both parties, the Division Bench of A. Muhamed Mustaque and Sophy Thomas, JJ., expressed that as per Section 25 of the Hindu Marriage Act, while awarding permanent alimony and maintenance, the husband’s income and other property, if any, and the income and property of the wife, conduct of the parties and other circumstances are to be taken into account.

Read full report here…

  • Consensual Sex

Can promise to marry a married woman be legally enforceable wherein she voluntarily formed sexual relations with a man?

Dr Kauser Edappagath, J., addressed a matter wherein a married woman voluntarily had sex with her former lover.

Read full report here…

  • Maintenance Tribunal

Whether power of Maintenance Tribunal under Senior Citizen Act is circumscribed to ordering of monthly allowance?

In a matter, wherein a senior citizen has approached the Court with her grievance with respect to her son, Murali Purushothaman, J., expressed that,

“When the Senior Citizen or parent who has earnings makes an application to the Maintenance Tribunal contending that her right to earning is obstructed by the son who has statutory obligation to maintain the parent, the Maintenance Tribunal has to ensure that the Senior Citizen or parent is able to maintain herself from her earnings.”

“To care for those who once cared for us is one of the biggest honours.”

Read full report here…

  • Family Court

Do Family Courts have to remain as a neutral umpire of the real dispute between the parties?

Expressing that, Family Court has been functioning in like manner of an ordinary Civil Court, the Division Bench of A. Muhamed Mustaque and Sophy Thomas, JJ., remarked that, family courts have to be impartial or neutral.

Dissatisfaction with the administration of justice in the Family Courts is writ large on the face of many orders challenged before this Court.

Read full report here…


Karnataka High Court


Mere suspicion is not enough to prosecute the petitioner for offence punishable under S. 370 of the IPC for human trafficking; Kar HC observes in a case where AIO caught 3 Indian nationals on suspicion

The Court after perusing complaint, charge sheet and Section 370 of the IPC observed that the petitioner had indulged himself in human trafficking and thus the soul of the provision is exploitation.

Read full report here…

  • Election

Kar HC quotes “The Vajpayee led NDA–Government was toppled for want of one vote” and Benjamin Franklin while deciding a case of a returning candidate whose election was set aside

“…A right to elect, fundamental though it is to democracy, is, anomalously enough, neither a fundamental right nor a Common Law Right. It is pure and simple, a statutory right. So is the right to be elected. So is the right to dispute an election.”

Read full report here…

  • Solid Waste Management

PIL filed seeking to shift the location identified for setting up solid waste management; directions issued

A Division Bench of Ritu Raj Awasthi CJ. and S. R Krishna Kumar JJ. issued directions regarding setting up of solid waste management units after expert opinion from concerned authorities.

Read full report here…

  • A&C Act

Kar HC deals whether an international commercial arbitral award rendered outside India between the parties who have no connection to India can be enforced in India

“…a foreign award under a New York Convention has been given a special status. India being a signatory to the said New York Convention it is required that all countries which are signatories to the New York Convention enable execution of a foreign arbitral award rendered in a reciprocating country in the event of a property against which the arbitral award is sought to be enforced is situated within the jurisdiction of that particular country.”

Read full report here…

  • Dishonour of Cheque

Kar HC decides contours of law in a classic case where cash of Rs 2 crore was borrowed as hand loan and a cheque obtained for the repayment of the same got dishonoured

The Court observed that the Act was amended by the Amendment Act of 2018 and Section 143A came to be inserted. The purport of the amendment is that the Court may in certain circumstances award interim compensation which shall not exceed 20% of the amount of the cheque and such interim compensation can be permitted to be withdrawn in terms of the said amendment.

Read full report here…


Madras High Court


  • Tax Liability

If an assessee under stress of investigation, signs a statement admitting tax liability and makes a few payments, can it lead to self-ascertainment?

Merely because an assessee has, under stress of investigation, signed a statement admitting tax liability and has also made a few payments as per the statement, cannot lead to self-assessment or self-ascertainment.

Read full report here…

  • Two-Finger Test

Ban the practice of two-finger test on victims of sexual offences by medical professionals

Stating that two-finger test cannot be permitted to be continued, the Division Bench of R. Subramanian and N. Sathish Kumar, JJ., directed the State Government to ban the practice of two-finger test on victims of sexual offences by the medical professionals.

Read full report here…

  • Co-parcenary Right

Are Coparcenary rights taken away by Hindu Succession Act?

Anand Venkatesh, J., addressed a matter with regard to coparcenary rights of sons and daughters

Read full report here…

  • Legal Profession

Law Officers perform their duties without profit motive and with a service mentality for a nominal fee as compared to their lucrative private practice

Expressing that, Legal profession is a noble profession, and it is the lawyer, who plays a predominant role in securing every citizen life and personal liberty fundamental and statutory rights ensured by the ConstitutionM. Govindaraj, J., observed that, Law Officers perform their duties without profit motive and with a service mentality for a nominal fee as compared to their lucrative private practice.

Read full report here…

  • Law of Limitation

Exercise of power of discretion if made excessively, it would defeat the purpose and object of law of limitation; Courts not to travel beyond permissible extent

Expressing that, Power of discretion is to be exercised to mitigate the injustice if any occurred to the litigantsS.M. Subramaniam, J., remarked that,

“Litigations/appeals are expected to be filed within the period of limitation as contemplated under the Statutes. Rule is to follow limitation. Condonation of delay is an exception. Exceptions are to be exercised discreetly, if the reasons furnished are genuine and acceptable.”

Read full report here…


Madhya Pradesh High Court


  • Live-in Relationships

Live-in relationships are engulfing ethos of Indian society, and promoting promiscuity and lascivious behavior, giving further rise to sexual offences

Subodh Abhyankar, J., expressed that, the bane of live-in-relationship is a by-product of the Constitutional guarantee as provided under Article 21 of the Constitution of India.

Read full report here…

  • Divorce

Woman is considered half of her husband and thus completes him. While a man is also considered incomplete without a woman; Appeal for divorce dismissed

“Based on Hindu law, marriage is a sacred tie and the last of ten sacraments that can never be broken. Also, it is a relationship that is established by birth to birth. Also, it is not only considered as sacred but it is also a holy union. The main objective of marriage is to enable a woman and a man to perform their religious duties. Along with this, they also have to beget progeny. Based on ancient writings, a woman is considered half of her husband and thus completes him. While a man is also considered incomplete without a woman.”

Read full report here…

  • Criminal Proceeding

Criminal proceeding maliciously instituted with an ulterior motive for wrecking vengeance deserves to be quashed; Court allows petition by husband

Rajeev Kumar Shrivastava, J. allowed a petition which was filed to quash FIR for offence under Sections 498-A, 506, 34 of IPC and other subsequent proceedings initiated therefrom.

Read full report here…

  • Bail

Warning issued to Additional Session Judge for granting bail on caste and bias

Vivek Agarwal, J. allowed a bail application issuing a warning to First Additional Session Judge, Maihar, District Satna to be more cautious and judicious in his approach in future so that image of the judiciary can be saved and allegations of casteism and bias are not allowed to be levied so to tarnish collective image of judiciary.

Read full report here…

  • Mental Cruelty

Mental cruelty inflicted by the wife over her husband through her conduct a valid ground for divorce; Court allows appeal

The Division Bench of Sheel Nagu and Anand Pathak, JJ., allowed an appeal which was preferred under Section 19 of the Family Court Act, 1984 against the judgment and decree dated 27-03- 2019 passed by the Link Family Court whereby the application preferred by the appellant/applicant/husband under Section 13(1)(iA) of Hindu Marriage Act, 1955 had been rejected.

Read full report here…

  • Dishonour of Cheque

Whether dishonour of cheques could have only given a cause of action to register an FIR for an offence under S. 420 IPC?

The Court stated it is a well-settled principle of law that the general law will not prevail over the Special Law as enshrined in the maxim generalia specialibus non derogant.

Read full report here…


Orissa High Court


  • Dishonour of Cheque

Ori HC considers whether any difference exists between a case where default is committed and prosecution immediately launched and where prosecution is deferred till cheque presented again gets dishonored for second or successive time?

R K Pattnaik, J. dismissed the petition and held that the ground on which the petition is raised is misconceived and therefore, cannot be sustained.

Read full report here…


Rajasthan High Court


  • Sexual Assault

Ex–fiancée levelled charges of sexual assault to harass and destroy present married life of the boy; Raj HC issues notice and directs police to neither harass nor arrest him

Dinesh Mehta, J., issues notice and directs police to neither harass nor arrest the petitioner boy.

Read full report here…

  • Bail

Raj HC granted temporary bail for a period of 15 days to enable the appellant to perform Kanyadaan on daughter’s marriage

A Division bench of Manindra Mohan Srivastava, CJ. and Madan Gopal Vyas J. allowed the application and granted bail for a period of 15 days.

Read full report here…

  • Mining Operations

PIL filed seeking permit for gypsum mining in the districts Shriganganagar and Haumangarh; Raj HC observes citizen does not have any vested right to carry on mining operations, absolute right lies with State

A Division Bench of Farjand Ali J and Sandeep Mehta JJ.  directed that as and when the gypsum mining operations are opened in Sriganganagar and Hanumangarh districts, the petitioners shall not be entitled to apply for mining licenses for this purpose in either of these two districts.

Read full report here…

  • Maintenance of Senior Citizens

Ill-treatment meted out to respondent-mother, expelled from her own house, allegations of mental, physical and social abuse; Raj HC directs petitioner-son to vacate the house with his family

The Court observed that Maintenance and Welfare of Parents and Senior Citizens Act, 2007 was enacted by the Legislature in the background that the traditional norms and values of the Indian Society are lost due to withering of the joint family system as a large number of elderly are not being looked after by their family, particularly the widowed women, who are forced to spend their twilight years all alone and are exposed to emotional neglect, lack of financial support and are rather treated as a waste.

Read full report here…

  • Right to Procreation

Raj HC reiterated “Right to Procreation survives during incarceration” and “is traceable and squarely falls within the ambit of Article 21 of our Constitution; Parole granted

The Division Bench of Farjand Ali and Sandeep Mehta, JJ. allowed the petition and granted parole after considering the religious philosophies, cultural, sociological and humanitarian aspects, coupled with the fundamental right guaranteed by the Constitution of India.

Read full report here…


Punjab and Haryana High Court


  • Duration of Marriage

Short duration of marriage cannot be the only ground to disallow organ transplant by spouse; writ petition allowed

 Raj Mohan Singh, J., contemplated the present petition and ruled that a short duration of marriage is absolutely no ground to deny an organ transplant.

Read full report here…

  • Mental Cruelty

Unworkable Marriage | Wife makes unfounded, indecent and defamatory allegations against husband to his senior officers, destroying his career & reputation: Mental Cruelty or not?

Expressing that, Matrimonial cases are matters of delicate human and emotional relationshipthe Division Bench of Ritu Bhari and Ashok Kumar Verma, JJ., expressed that, the Court no doubt should seriously make an endeavour to reconcile the parties, yet, if it is found that the breakdown is irreparable, then divorce should not be withheld.

Read full report here…

  • Voice Sample

S. 65-B (4) of the Evidence Act does not mention the stage of furnishing the certificate for admissibility; Court directs to give voice sample

Avneesh Jhingan, J., entertained a petition under Section 482 CrPC where the petitioner was aggrieved by the directions of the Chief Judicial Magistrate for giving voice samples.

Read full report here…


Telangana High Court


  • Employees State Insurance Act

Exhausting the remedy available for appeal is the rule and entertaining a writ petition is an exception

G Radha Rani, J., disposed of the petition and directed the petitioner to approach the EI Court under Section 75 of the ESI Act by filing an appropriate application.

Read full report here…


Tripura High Court


  • POCSO

Offence under S. 8 of the POCSO Act not been established beyond reasonable doubt; Court acquits man of POCSO charges

Arindam Lodh, J. partly allowed an appeal which was filed against the judgment and order of conviction whereby and whereunder the appellant has been found guilty for committing an offence punishable under Section 8 of the POCSO Act and sentenced him to suffer Rigorous Imprisonment for 3 years for the said offence and also found guilty under Section 448 of IPC and sentenced to suffer Rigorous Imprisonment for 1 year for the said offence.

Read full report here…

Statement of the victim show exaggerations and improved versions; Court reduces sentence in POCSO matter

Arindam Lodh, J. partly allowed an appeal which was filed challenging the judgment of conviction and order of sentence passed by Special POCSO judge wherein the appellant had been convicted under Section 10 of the POCSO Act, 2012 and sentenced to suffer rigorous imprisonment for 5 years and to pay a fine of Rs 20,000/- with default stipulation and further convicted under Section 451 IPC and sentenced him to suffer simple imprisonment for 6 months and to pay fine of Rs. 5000 with default stipulation.

Read full report here…


Sikkim High Court

State directed to ensure immediate escalation of progress of work of repairing of NH-10; meeting called to chalk out the immediate course of action before monsoon arrival

The Division Bench of Biswanath Somadder and Meenakshi Madan Rai, JJ. took up the PIL in order the peruse the status report concerned with the damaged roads and highways in the State.

Read full report here…

  • Missing Children

Directions issued for tracing out the missing children in the State; CCTV’s installed in police stations

The Division Bench of Biswanath Somadder, CJ. and Meenakshi Madan Rai, J. issued certain directions in the matter of a PIL concerning missing children in the State.

Read full report here…

High Court Round UpLegal RoundUpTribunals/Regulatory Bodies/Commissions Monthly Roundup

Interesting Stories of the Week


[Media Trial] Can media be given right to speculate on outcome of one going investigations or Court proceedings or criminal trials? Ker HC elucidates

While addressing the matter with regard to the media trial, Mohammed Nias C.P., J., expressed that, half-truths and misinformation cannot be the basis of publications or telecasts7.

Reports/telecast having the effect of prejudicing mankind against the parties and the court before the case is heard clearly interferes with the course of justice.

Read more here: https://bit.ly/37DrXKX


Whether denial of sex can qualify as “exceptional depravity” under S. 14 of the Hindu Marriage Act and allow waiver of one-year mandatory period? Del HC unfolds

Noting that, Section 14 of the Hindu Marriage Act intends to discourage the couples from breaking the sacred bond of marriage in haste, the Division Bench of Vipin Sanghi, ACJ and Jasmeet Singh, J., held that, a mandatory one year period granted under Section 14 of the Act, encourages couples to cool down, and give a rethink to preserve their marriage.

Read more here: https://bit.ly/3v5iYen


Can children claim any amount under the head of permanent alimony under S. 25 of Hindu Marriage Act? Ker HC explains

Observing that trauma in a marital discord is common to both parties, the Division Bench of A. Muhamed Mustaque and Sophy Thomas, JJ., expressed that as per Section 25 of the Hindu Marriage Act, while awarding permanent alimony and maintenance, the husband’s income and other property, if any, and the income and property of the wife, conduct of the parties and other circumstances are to be taken into account.

Read more here: https://bit.ly/3EAH18c


Child marriages will have to be stopped and no person can be allowed to take advantage of any such situation: Bom HC

Vibha Kankanwadi, J., expressed that Child marriages are hazardous to the social fabric of this Country.

Read more here: https://www.scconline.com/blog/post/2022/04/16/child-marriages/


Past pregnancy can be determined on account of permanent changes in the body of a woman: Bom HC

While addressing a matter, wherein the accused who was a doctor charged for raping a minor stated that there was not any proof that the girl ever conceived or had undergone any abortion, M.G. Sewlikar, J., expressed that, Medical science is so advanced that now a days past pregnancy also can be determined on the basis of changes in the body of a woman on account of pregnancy.

Read more here: https://bit.ly/3v4cuwb


Can minority members of a Society act against will of majority members and foist delay in commencement of redevelopment work of Society? Bom HC addresses

Observing that, a developer who has been appointed by the Society and who is eager to proceed with the redevelopment, was in some manner left baffled and dragged into litigationG.S. Kulkarni, J., held that, non-cooperating members cannot foist a delay on the builder and the society in the commencement of the redevelopment work resulting in the project costs being increased every passing day.

Read more here: https://bit.ly/3ED6cHa


Live-in relationships are engulfing ethos of Indian society, and promoting promiscuity and lascivious behavior, giving further rise to sexual offences: Madhya Pradesh HC

Subodh Abhyankar, J., expressed that, the bane of live-in-relationship is a by-product of the Constitutional guarantee as provided under Article 21 of the Constitution of India.

Read more here: https://bit.ly/3Os1ocf


Can filing of a maintenance proceeding, a criminal case for harassment be said to be sufficient to jump to a conclusion that wife intended to harass husband and his relations? Bom HC throws light

In a matter of matrimonial discord, Mangesh S. Patil, J., expressed that, when admittedly, for whatever reason, there was a marital discord and the wife had started residing with the infant child at her parental house barely within three years of her marriage, it cannot be expected of her not to prosecute whatever rights and remedies she has under the law.

Read more here: https://bit.ly/3ECAiuk


Only continuous and repeated acts of adultery and/or cohabitation in adultery would attract rigours of provision under S. 125(4) CrPC: Del HC

While addressing a matter with regard to a wife’s right to maintenance Chandra Dhari Singh, J., expressed that, only continuous and repeated acts of adultery and/or cohabitation in adultery would attract the rigours of the provision under Section 125(4) CrPC.

Read more here: https://bit.ly/37DrUPh


When a Judge recuses without reasons, can a litigant or third party intervene, comment or enquire? Del HC answers

Asha Menon, J., held that, when a Judge recuses, no litigant or third party has any right to intervene, comment or enquire. The recusal has to be respected, whether a reason has been spelt out in detail or not.

Read more here: https://bit.ly/3v4AvDq


Sudden cancellation of rooms booked for daughter’s marriage 3 months prior on account of maintenance: Is it an acceptable reason? Can consumers claim compensation? NCDRC explains

“The memories of marriage ceremonies are lifetime events in the life of bride and bridegroom and their family members to make their moments memorable. In our country, certainly, it is not an easy task for the parents to arrange their daughter’s marriage in a five-star hotel in place like Jaipur or any big cities. All of sudden cancellation of booking about 3 months prior to the date of marriage on account of maintenance is not acceptable reason.”

Read more here: https://bit.ly/3K2xpnH

Case BriefsHigh Courts

Punjab and Haryana High Court: Expressing that, Matrimonial cases are matters of delicate human and emotional relationship, the Division Bench of Ritu Bhari and Ashok Kumar Verma, JJ., expressed that, the Court no doubt should seriously make an endeavour to reconcile the parties, yet, if it is found that the breakdown is irreparable, then divorce should not be withheld.

In the present matter, husband-appellant approached the Court seeking to set aside the decision of the District Judge whereby the petition filed by him under Section 13 of the Hindu Marriage Act, 1955 for dissolution of marriage had been dismissed.

Factual Background


The Husband sought dissolution of the marriage on the ground that the wife from the beginning of the marriage was cruel, and harsh and she used to pick up quarrels over trifles without any justifiable cause. Further, the respondent-wife deserted the appellant-husband in 2002 and since then she had not returned to the matrimonial home.

Whenever, the appellant went to meet from his place of posting to meet his wife, the wife’s parents did not allow him to meet the son and wife both. Later, in the year 2006, when the husband requested the wife to company her, she refused stating that is he tried to take her she would commit suicide.

In spite of best efforts, the respondent did not join the matrimonial home, he was compelled to institute a divorce petition. Further, despite giving undertaking before the Court that she would withdraw her complaint and maintenance application file before the Senior Air Force Officer, she did not do so and did not join the company of the appellant, hence, the decree of divorce was sought.

Analysis, Law and Decision


“The institution of marriage occupies an important place and role to play in the society, in general.”

High Court noted that the criminal complaint was made by the wife after the filing of the divorce petition by the husband, however, the fact remained that earlier also she had filed complaints against the appellant before his senior officers in the Air Force which she assured to withdraw.

Filing of the complaint and initiation of criminal proceedings which were found to be baseless and false, do cause harassment and torture to the husband and his family, Bench stated.

Noting that the wife’s conduct of filing a complaint making unfounded, indecent and defamatory allegations against her husband and parent-in-law Bench stated that the same caused mental cruelty.

Respondent wife also bent upon destroying the career and reputation of the appellant-husband as she made complaints against him to his senior officers in the Air Force.

Primary Issue for Consideration


Whether the relationship of the husband and wife has come to an end and if the respondent-wife is not ready to give mutual divorce to the appellant-husband, whether this act of her, would amount to cruelty towards husband, keeping in view the fact that she is not staying with her husband for the last twenty years and there is no scope that they can cohabit as husband and wife again?

This Court along with several decisions also referred to the Supreme Court in Naveen Kohli v. Neetu Kohli, (2006) 4 SCC 558, wherein the Court considered a case of irretrievable break down of marriage. In this case, the wife was living separately for long but did not want a divorce by mutual consent, only to make life of her husband miserable. Thus, the decree of divorce was granted and held a cruel treatment and showed that the marriage had broken irretrievably.

In the instant case as well, the Bench found that marriage had broken down irretrievably and there was no chance of their coming together or living together again. Hence, not granting a decree of divorce would be disastrous.

The consequences of preservation in law of the unworkable marriage which has long ceased to be effective are bound to be a source of greater misery for the parties.

Lastly, in Court’s opinion, the appeal should be allowed, and the decision of the District Judge be set aside and a decree of divorce be granted. The husband was directed to make an F.D. of Rs 20 lakhs as permanent alimony in the name of the respondent-wife.[Devesh Yadav v. Meenal, 2022 SCC OnLine P&H 902, decided on 8-4-2022]


Advocates before the Court:

Mr. Gurpreet Singh, Advocate, for the appellant-husband.

Mr. Gautam Diwan, Advocate, for the respondent-wife.

High Court Round UpLegal RoundUpTribunals/Regulatory Bodies/Commissions Monthly Roundup

Interesting picks from this week’s legal stories from High Courts to District Courts


Alimony


Whether husband is entitled to claim alimony under Section 25 of the Hindu Marriage Act, 1955? Bom HC decides

A conjoint reading of Sections 24 and 25 of the Hindu Marriage Act, 1955 would reveal that both the sections in the Act of 1955 are enabling provisions and confer a right on the indigent spouse to claim maintenance either pendente lite or in the nature of permanent alimony and maintenance.

Read full report here…


 Karta


 Daughters and widow of a deceased would inherit properties of deceased as tenants in common or joint tenants? Bom HC explains 

Mangesh S. Patil, J., expressed that, by virtue of Section 19 of the Hindu Succession Act, it has been explicitly made clear that if two and more heirs succeed together to the property and in the estate, they take the property as tenants in common and not as joint tenants.

Read full report here…


Compassionate Appointment


Illegitimate child’s right to be considered for Compassionate appointment: Read what Chh HC says

Sanjay K. Agarwal, J., held that an illegitimate son would be entitled to consideration on compassionate ground and cannot be denied consideration on the ground that he is the illegitimate son of the deceased Government servant.

Read full report here…


Marriage Expenses


Can unmarried daughters claim expenses of marriage from their parents under the Hindu Adoptions and Maintenance Act, 1956? Chh HC addresses

While stating that, in Indian society, normally expenses are required to be incurred for pre-marriage and also at the time of marriagethe Division Bench of Goutam Bhaduri and Sanjay S. Agrawal, JJ., held that unmarried daughters have a right to claim expenses of marriage from their parents under the Hindu Adoptions & Maintenance Act, 1956.

Read full report here…


Maternity Leave


Can maternity leave benefits extend beyond the period when contractual period of an ad hoc employee comes to an end? Del HC analyses

In a claim of maternity benefit by a contractual employee, the Division Bench of Rajiv Shakdher and Talwant Singh, JJ., expressed that, The Maternity Benefit Act, 1961 Act is a social legislation that should be worked in a manner that progresses not only the best interest of the women-employee but also of the child, both at the pre-natal and post-natal stage.

Read full report here…


Strikes


Bar on Government servants to engage in strikes? Ker HC elaborates

While expressing that, it is the duty of the welfare Government to protect not only the citizens but to continue with, all the Government work as expected, the Division Bench of S. Manikumar, CJ and Shaji P. Chaly, J., directed that Government servants should be prevented from engaging in a strike.

Read full report here…


Evidentiary Value of Newspaper Reports


Newspaper reports are of no evidentiary value and Courts would be transgressing their well-settled limitation if cognizance were to be taken of such unsubstantiated and unverified reports

In a matter wherein, details were sought with regard to Supreme Court Collegium meeting held on 12-12-2018, Yashwant Varma, J., expressed that, newspaper reports are of no evidentiary value and Courts would be clearly transgressing their well-settled limitation if cognizance were to be taken of such unsubstantiated and unverified reports.

Read full report here…


Anand Marriage Act


State directed to take steps to frame and notify Rules for Registration of Sikh Marriages

The Division Bench of Sanjaya Kumar Mishra, ACJ. and Ramesh Chandra Khulbe, J. took up a PIL filed by the petitioner commanding the respondent State to notify the Rules under Anand Marriage Act, 1909 and also to issue guidelines to register the marriage of people of Sikh Community under the Anand Marriage Act, 1909.

Read full report here…


Bribes


Every Advocate is a Court officer and part & parcel of the justice delivery system: Madras HC found a Govt. Advocate demanding bribes at the cost of justice

The Division Bench of K. Kalyanasundaram and R. Hemalatha, JJ., expressed that, the Government advocate being the representative of the Government has to act in an honest manner. If he/she goes around with the intention to make money at the cost of justice, only chaos will prevail.

Read full report here…


Insolvency


Logix Insolvent? NCLT initiates insolvency proceedings against Logix City Developers

The Coram of Bachu Venkat Balaram Das (Judicial Member) and Narender Kumar Bhola (Technical Member) initiates insolvency proceedings against Logix City Developers due to default in payment.

Read full report here…


Custody Parole


Merely because an accused is a Muslim, governed by personal laws, can be debarred from availing rights under Juvenile Justice (Care and Protection of Children) Act, 2000? Delhi Court answers

In a matter for grant of custody parole, Dharmender Rana, ASJ-02, held that, merely because the accused is Muslim and governed by personal laws, he cannot be debarred from availing rights conferred upon him by Juvenile Justice (Care and Protection of Children) Act, 2000.

Read full report here…

Case BriefsHigh Courts

Bombay High Court: Bharati Dangre, J., held that provision of maintenance/permanent alimony being a beneficial provision for the indigent spouse, Section 25 can be invoked by either of the spouse, where a decree of any kind governed by Sections 9 to 13 has been passed and marriage tie is broken, disrupted or adversely affected by such decree of the court.

Petitioner-Wife on being aggrieved by the order of the Civil Judge approached this Court.

Respondent-husband had filed Hindu Marriage Petition claiming for grant of permanent alimony from the petitioner-wife at the rate of Rs 15,000 per month. The said application was filed under Section 25 of the 1955 Act, wherein it was pleaded that since the respondent-husband had no source of income and on the contrary, the petitioner-wife had acquired the educational qualification of M.A., B.Ed and was serving at Shri Datta Mahavidyalaya, Talni, Taluka Hadgaon.

It was stated that, in order to encourage the wife to obtain the degree, the husband managed the household affairs, keeping aside his own ambition.

Respondent-husband pleaded that he suffered humiliation and harassment in the marital relationship as the petitioner-wife, with a malafide and dishonest intention, filed petition that the respondent was neither doing any job, nor does he possess any moveable or immovable property or had any independent income.

Respondent-husband claimed maintenance of Rs 15,000 per month from the wife.

Analysis, Law and Decision

High Court expressed that a conjoint reading of Sections 24 and 25 of the Hindu Marriage Act, 1955 would reveal that both the sections in the Act of 1955 are enabling provisions and confer a right on the indigent spouse to claim maintenance either pendente lite or in the nature of permanent alimony and maintenance.

The words applied in Section 25 of the Act of 1955 permit any court exercising jurisdiction under this Act, i.e. under Sections 9 to 13, at the time of passing any decree or at any time subsequent thereto, on an application made to it, by either of the spouse pay to the applicant for her/his maintenance, either gross sum or monthly or periodical sums for not exceeding the life of the applicant, having regard to the income and the other property, etc.

Bench clarified that the term used “at any time subsequent thereto” cannot be made redundant, by giving constricted meaning to the words “wife or husband”.

Sub-sections (2) and (3) of Section 25 are indicative of the fact that if at the time of decree, an application is made or at any subsequent time of the passing of the decree, an application is made, claiming maintenance by either of the spouse, the Court is empowered to grant the claim, which is just and proper and the payment can be secured if necessary, by creating charge on the immovable property of the respondent.

Further, the Bench added that Section 25 is not only restricted to a decree of divorce, but the decree can also be for restitution of conjugal rights under Section 9, the decree can also be for judicial separation under Section 10, or the decree can also be for divorce under Section 13 or the decree can also be for a divorce by mutual consent under Section 13B.

Additionally, the Court expressed that,

Scope of Section 25 of the Act of 1955 cannot be constricted by not making it applicable to a decree of divorce being passed between the husband and wife.

Lastly, the High Court remarked that,

“Since Section 25 has to be looked upon as a provision for destitute wife/husband the provisions will have to be construed widely so as to salvage the remedial intailments.”

“…the application for interim maintenance filed under Section 24 of the Act of 1955, has been rightly entertained by the learned Judge and the husband has been held entitled to interim maintenance while the proceedings under Section 25 are pending.”

In view of the above impugned order were upheld and the petitions were dismissed. [Bhagyashri v. Jagdish, 2022 SCC OnLine Bom 694, decided on 26-2-2022]


Advocates before the Court:

Mr S.S. Thombre for the petitioner.

Mr Rajesh Mewana for respondent 1.

Case BriefsSupreme Court

Supreme Court: In a divorce proceeding, where a wife had “rejected” all the options for rented accommodation “similar” to her Industrialist husband’s residence, the bench of L. Nageswara Rao and BR Gavai*, JJ has held that the conduct of the wife in firstly, not choosing any house as per her choice and secondly, in rejecting all the properties, which have been identified by the Architect, only on the ground that they are not similar, to say the least is “unreasonable”.

Case Trajectory

  • The husband, Industrialist Jaidev Shroff and his wife Poonam, got married on November 27, 2004. However, the relationship between them soured and various cases including the FIRs were filed by both the husband and wife against each other.
  • The husband filed a divorce petition in 2015 seeking divorce on the ground of cruelty. He also lodged a complaint making certain serious allegations against the wife, after which she voluntarily left the Pali Hill Bandra residence where the husband and wife residing and went to live at her mother’s residence with her daughter.
  • The husband thereafter filed an application seeking an order of injunction restraining the wife from entering the said house. While the Family Court granted an injunction restraining the wife from entering the said house, the Bombay High Court allowed the writ petition filed by the wife.
  • The husband, hence, moved the Supreme Court.
  • Exploring the possibility of an amicable resolution, mediators were appointed twice. However, both the time, the mediators submitted that it was not possible to resolve the matter.
  • On 6 th March 2020, the Supreme Court passed the following order directing the Registrar of the Family Court to engage an architect from the panel of architects maintained by the Bombay High Court for finding out appropriate rented accommodation for the residence of the wife. It is made clear that the residence shall be approximately ‘similar’ to the size of the Pali Hill residence and located as far as possible in Bandra and Juhu area.
  • While the Architect gave a list of as many as 17 properties, the wife rejected all saying that none of the properties shown in the list were similar to the said house.

Analysis

On possibility of shared household

The relations between the parties are strained to such an extent that even the efforts made by this Court to arrive at a settlement by personally discussing the matter in Chambers with them, have failed. On two occasions, the Court appointed Mediators but the mediation proceedings could not succeed. In such a situation, to compel the parties to live together in one house, would not be in the interest of either of the parties.

“With the history of such acrimony and filing of criminal cases against each other, such an order, rather than benefiting the parties, would be detrimental to their interests.”

On what would be a ‘similar’ property

To stretch the word ‘similar’ as used in the order dated 6th March 2020, to be totally identical to the said house, would be unrealistic. It will be difficult to find out a house identical to the said house having the same area, the same facilities and the same luxuries. The word ‘similar’ has to be construed as providing the same degree of luxury and comfort as is available in the said house. Hence,

“… the conduct of the respondentwife in firstly not choosing any house as per her choice and secondly, in rejecting all the properties, which have been identified by the Architect, only on the ground that they are not similar and therefore, not in accordance with the order dated 6th March 2020, to say the least is unreasonable.”

On payment of Rs.35.37 lakhs per month by husband

It was argued by Senior Advocate Shyam Divan, appearing for the wife, that the husband is earning   hundreds of crores per year, whereas the wife and the daughter have to survive on a meagre amount of Rs. 12 lakhs per month, hence, payment of Rs.35.37 lakhs per month should be paid.

The Family Court, by an elaborate order, after recording the details about the income of the parties, had directed an interim maintenance to be paid to the wife at the rate of Rs. 7 lakhs per month and to the minor at the rate of Rs. 5 lakhs per month.

It was, hence, noticed that if the prayer for payment of an amount is allowed, it will be giving an additional amount to the wife. It will amount to awarding an amount which is much more than the one to which the wife was found entitled by the Family Court.

Order

The Court held that if the wife decides to shift to any of the properties listed by the Architect or if she locates any of the rented premises as per her choice, the husband shall pay the rent of the said premises from the date on which such premises are taken on rent. However, taking into consideration that the highest rent of the properties identified by the Architect is Rs. 30 lakhs per month, the husband would be liable to pay rent to the maximum of Rs. 30 lakhs per month.

Further, considering that the divorce petition has been pending before the Family Court for a period of last 6 years, the Court directed that the divorce petition pending before the Family Court be decided expeditiously so that there can be at least some quietus to the acrimonious litigation pending between the parties.

[Jaidev Rajnikant Shroff v. Poonam Jaidev Shroff, 2021 SCC OnLine SC 1175, decided on 03.12.2021]


Counsels

For wife: Senior Advocate Shyam Divan

For Husband: Senior Advocate Dr. Abhishek Manu Singhvi


*Judgment by: Justice BR Gavai 

Case BriefsHigh Courts

Punjab and Haryana High Court:  In a revision petition filed against the enhanced amount of alimony H.S. Madaan, J., upheld Family Court’s decision that,

If salary of the husband increases the wife would be entitled to increased maintenance as well.

The Petitioner, one Varun Jagotta had filed the instant revision petition against his wife Diksha Kapur, feeling aggrieved by the order of the Family Court whereby the Court had granted interim maintenance at Rs 20,000  per month till September, 2019 and thereafter at Rs 28,000 per month. The petitioner was basically aggrieved by the portion of the impugned order granting maintenance at Rs 28,000 w.e.f. October, 2019 onwards.

Taking note of the fact that there had been increase in the salary of the respondent from Rs 95,000 per month to Rs 1,14,000 per month in September, 2019 and there had been increase in rent being paid by the petitioner at the rate of Rs.1,500 per month, the Family Court opined that  if the petitioner is awarded a sum of Rs 20,000/- per month by way of interim maintenance from the date of filing the application (on 03.10.2018) till September, 2019 and henceforth, at the rate of Rs 28,000/- per month, it would suffice the purpose and ends of justice would be met.

The petitioner contended that as per pay slip of the petitioner for the month of December, 2019, his net carry home salary after all the deductions came out to Rs 92,175, therefore, grant of maintenance at Rs 28,000 per month was not justified.

Noticing that salary of the petitioner had increased from Rs 95,000 per month to Rs 1,14,000 per month, the Bench held that,

 “Increase in maintenance by Rs.8,000 when there was increase in salary of revision petitioner by 19,000, was justified.”

Hence, it was held that the impugned order did not suffer from any illegality or infirmity and was not perverse or passed in an arbitrary manner. The instant petition was dismissed. [Varun Jagotta v. Diksha Kapur, CRR(F)-28 of 2021, decided on 05-02-2021]


Kamini Sharma, Editorial Assistant has put this story together.

Banking and Negotiable InstrumentsHigh Court Round UpLegal RoundUp

In our series of 2020 wrap-ups, let’s revisit and take a dive at some of our stories on family laws and how different High Courts dealt with the same involving some very significant rulings.

We have listed down Case briefs under sub-categories, of our coverage under the Family Law and its allied provisions.


Allahabad High Court

Custody of Minor

In minor’s custody case, where child is below 5 years of age, mother is preferred, but is there any exception to it? All HC explains

[Meenakshi v. State of U.P., 2020 SCC OnLine All 1475, decided on 02-12-2020]

If a natural guardian faces criminal charges relating to death of spouse, can custody of children or visitation rights be granted? All HC discusses

[Shaurya Gautam v. State of U.P., 2020 SCC OnLine All 1372, decided on 10-11-2020]

Decree of Eviction against Son

Can daughter-in-law be evicted without seeking decree of eviction against the son under S. 2(s) of Domestic Violence Act? All HC answers

[Sujata Gandhi v. S.B. Gandhi, 2020 SCC OnLine All 763, decided on 12-06-2020]


 Bombay High Court

Alimony

If the wife is earning something for livelihood, can the same be a ground to refuse alimony under S. 24 of Hindu Marriage Act? Read Bom HC’s ruling reiterating SC’s decision

[Arpana Vijay Manore v. Dr Vijay TukaramManore, 2020 SCC OnLineBom 3925, decided on 09-12-2020]

Bigamy

Person committing offence under S. 494 IPC, must have married another woman or man during subsistence of his or her first marriage; Bom HC invokes power under S. 482 CrPC to meet ends of justice

[Rekha v. State of Maharashtra, 2020 SCC OnLineBom 291, decided on 13-02-2020]

 Cooling-off Period

Can “cooling-off period” under S. 13-B(2) of Hindu Marriage Act be waived? Legal position discussed in a case of pregnant woman

[Kovelamudi Kanika Dhillon v. Kovelamudi Surya Prakash Rao,  2020 SCC OnLineBom 2054, decided on 26-10-2020]

 Cruelty to Woman

Abuse of S. 498-A IPC by making vague allegations and roping in family members of husband: Courts to carefully scrutinize allegations

[Shabnam Sheikh v. State of Maharashtra, 2020 SCC OnLineBom 1752, decided on 15-10-2020]

“Easy to accuse somebody of ill-treatment after someone dies, but not wise to convict somebody based on general statements”: Bom HC holds every cruelty is not an offence under S. 498-A IPC

[State of Maharashtra v. Shri Balu Ravji Abhang, 2020 SCC OnLineBom 307, decided on 20-02-2020]

Family members should not be dragged without specific evidence against them, otherwise, S. 498-A IPC is unfortunately misused as a weapon, says Bom HC

[State of Maharashtra v. Ashok, 2020 SCC OnLineBom 331, decided on 26-02-2020]

 Custody of Minor

Welfare of child as paramount consideration: Bom HC gives custody to father of minor for mother not being able to take care of the child

[Sashanka v. Prakash, 2020 SCC OnLineBom 3497, decided on 27-11-2020]

Domestic Violence & Jurisdiction of Courts

Does Family Court has jurisdiction to entertain an application for relief under Ss. 18 to 22 of DV Act? Read what Bom HC held

[Hitesh Prakashmalji Mehta v. Aashika Hitesh Mehta, 2020 SCC OnLineBom 983, decided on 28-09-2020]

Second Marriage

Performing second marriage during pendency of an appeal is a breach under S. 15 of HMA, but would it amount to civil contempt? Bom HC analyses

[Kanchan v. Prashant Manikrao Bagade, 2020 SCC OnLineBom 911, decided on 08-09-2020]

 Unmarried Daughter (Maintenance)

Whether unmarried daughter who is major by age, entitled to claim maintenance from father till her marriage? Bom HC explains law in light of Hindu Adoption & Maintenance Act

[Sanjay J. Phagnekar v. State of Maharashtra, 2020 SCC OnLineBom 3382, decided on 23-11-2020]

Widowed Daughter-in-Law (Maintenance)

Can a widowed daughter-in-law claim maintenance from the estate inherited by her father-in-law? Law explained

[Sardool Singh Sucha Singh Mathroo v. Harneet Kaur, 2020 SCC OnLineBom 927, decided on 07-09-2020]

 Wife having Independent Source of Income (Maintenance)

[S. 125 CrPC] Wife cannot be denied maintenance on ground of having a source of income: Restated by Bom HC

[Sanjay Damodar Kale v. Kalyani Sanjay Kale, 2020 SCC OnLineBom 694, decided on 26-05-2020]


Calcutta High Court

Child Marriages

Alarming rise of child marriages during lockdown has given a strong impression that they may be in garb of child trafficking; Police to investigate

[Contagion of COVID-19 Virus in Children, In Re., 2020 SCC OnLine Cal 1066, decided on 25-06-2020]

 Harassment over Complexion

Harassment by in-laws for woman’s black complexion is cruelty under S. 498-A IPC; Husband convicted for murdering wife over her black complexion

[Mazidul Miah v. State of W.B., 2020 SCC OnLine Cal 1077, decided on 25-06-2020]


Chhattisgarh High Court

Alienation of Property by Alleged Wife

Whether alienation of property by an alleged wife of a deceased is void? Chh HC analyses position in light of ‘Customs’ under Hindu Marriage Act

[Anirudh Prasad Kamal Sen v. Dashmat Bai Suryavanshi, Second Appeal No. 93 of 2009, decided on 28-08-2020]

Cause of Action

In a matrimonial dispute, cause of action can arise several times, even if the dispute is settled and case has been withdrawn

[Harsha Dewani v. Ashutosh Gupta, 2020 SCC OnLineChh 149, decided on 10-08-2020]


Delhi High Court

Adultery

Adultery can only be committed after marriage, allegation of having relationship before marriage cannot be a ground of adultery; Divorce petition dismissed

[Vishal Singh v. Priya, 2020 SCC OnLine Del 638, decided on 12-06-2020]

Affidavit of Assets, Income and Expenditure

Del HC updates Affidavit of Assets, Income & Expenditure to be filed at threshold of matrimonial disputes; Issues modified directions [Detailed Report: Read Directions]

[Kusum Sharma (5) v. Mahinder Kumar Sharma, 2020 SCC OnLine Del 931, decided on 6-8-2020]

Cruelty & Desertion

Del HC analyses “A typical case that showcases as to what would amount to cruel behaviour on part of one spouse to utter detriment of other”

[Venkatesh Narasimhan v. V. Sujatha, 2020 SCC OnLine Del 571, decided on 01-05-2020]

Divorce Proceedings

Husband citizen and domicile of USA, Can he raise objections on divorce proceedings filed by wife in India? Del HC decrypts the law in light of catena of SC decisions

[Karan Goel v. Kanika Goel, 2020 SCC OnLine Del 1319, decided on 12-10-2020]

 Impotency

Is making false allegation of impotency by wife against husband a ground for decree of divorce? Del HC determines

[Kirti Nagpal v. Rohit Girdhar, 2020 SCC OnLine Del 1466, decided on 20-11-2020]

Maintenance

If interim maintenance by wife has already been secured under Domestic Violence Act, will application under S. 125 CrPC be maintainable? Del HC answers

[Rani v. Dinesh, Crl. Rev. P. 1091 of 2019 and Crl. M.A 13677 of 2020, decided on 02-12-2020]

Matrimonial Disputes

Del HC reiterates SC’s position on “duty of the Courts to encourage genuine settlements of matrimonial disputes”

[Harish Kumar v. State, 2020 SCC OnLine Del 1635, decided on 04-12-2020]

 Remedy against Custody Orders

“No exception to remedy against orders of custody under Domestic Violence Act”: Del HC dismisses S. 482 CrPC petition in view of S. 29 DV Act

[Srisha Dinav Bansal v. Rajiv Bansal, 2020 SCC OnLine Del 764, decided on 20-07-2020]

Right to Privacy versus Right to Fair Trial

[S. 14 of Family Courts Act] In a contest between right to privacy and right to fair trial, both of which arise under expansive Art. 21, right to privacy may have to yield to right to fair trial

[Deepti Kapur v. Kunal Julka, 2020 SCC OnLine Del 672, decided on 30-06-2020]

Second Marriage & Custody of Children

Second marriage of a mother is by itself not sufficient to deprive her of custody of her biological child

[Faisal Khan v. Humera,  2020 SCC OnLine Del 572, decided on 1-5-2020]

Settlement Deed affecting Children’s Right to Maintenance

Is it lawful for a wife to agree to a settlement deed in the process of dissolution of marriage wherein she settles that her minor children will not claim maintenance in future? Court explains

[Vashno Jaishwal v. State (NCT of Delhi), 2020 SCC OnLine Del 1504, decided on 20-11-2020]


Gauhati High Court

 Conjugal Life

Refusal to wear “sakha and sindoor” is clear intention that a hindu wife is unwilling to continue conjugal life: Divorce decreed to husband

[Bhaskar Das v. Renu Das, 2020 SCC OnLineGau 2954, decided on 19-06-2020]

 Maintenance

If a woman is divorced, will her status as a wife entitling her to maintenance under S. 125 CrPC change? Read Gau HC’s position

[Bijoy Seal v. Sefali Seal, 2020 SCC OnLineGau 4024, decided on 30-09-2020]

Special Marriage Act

If a marriage is first solemnised under the Special Marriage Act and later upon conversion to Islam, marriage is again solemnised under Mohammedan Law: Which law will prevail for dissolution of marriage? Gau HC to consider

[Md Makfur Rahman v. Malina Deb Barman, 2020 SCC OnLineGau 4645, decided on 23-04-2020]


Gujarat High Court

Permanent Alimony to a Muslim Woman

Will permanent alimony granted to a Muslim woman be conditional to her remarriage? Detailed report untangling significance of ‘Permanent Alimony’ & ‘Periodical Maintenance’

[Tarif Rashidbhai Qureshi v. Asmabanu, 2020 SCC OnLineGuj 711, decided on 19-03-2020]

Special Marriage Act

If marriage is registered under Special Marriage Act, is it necessary for the couple to take recourse of same law to sever ties permanently? Guj HC elucidates in a custody matter

[Chavda Twinkle v. State of Gujarat, 2020 SCC OnLineGuj 1167, decided on 17-07-2020]


Himachal Pradesh High Court

Ancestral Property

Can wife claim maintenance under S. 12 of the Protection of Women from Domestic Violence Act, 2005 over ‘ancestral property’ of the husband? HP HC explains

[Kubja Devi v. Chhape Ram,  2020 SCC OnLine HP 1829, decided on 05-10-2020]


Jharkhand High Court

Desertion

‘Desertion’ has to be wilful and voluntary for a valid ground for divorce under S. 13 of Hindu Marriage Act, 1955; Legal principle “No one can take a benefit of his own fault” applied

[Sanjay Kumar v. Suman Kumari, 2020 SCC OnLineJhar 773, decided on 08-09-2020]


Karnataka High Court

Cruelty to First Wife

Though Shariat permits a Muslim man to practise polygamy, but would that amount to cruelty to first wife? Kar HC explains concept of Marital Cruelty

[Yusufpatel v. Ramjanbi, MFA No. 201154 of 2018 (FC), decided on 17-08-2020]


 Kerala High Court

Convenience & Welfare of Children over Wife

In matrimonial matters preference is to be given to convenience and welfare of children over wife: Ker HC dismisses application for transfer of case

[Nimi v. Ajith M.T., 2020 SCC OnLine Ker 4313, decided on 09-10-2020]

Cruelty

Wife’s persistent effort to separate husband from family amounts to cruelty: Divorce granted in favour of husband

[Ranjith P.C. v. Asha Nair. P, 2020 SCC OnLine Ker 1751 , decided on 20-05-2020]

 Dowry

Is there a limitation period for wife to claim property entrusted to in-laws given in form of dowry? Ker HC answers

[Sheela K.K. v. N.G. Suresh, 2020 SCC OnLine Ker 4240, decided on 24-09-2020]

 Suppressing Material Facts & Marriage

If a wife obtains husband’s consent for marriage by suppressing material facts like cardiac ailments, would that amount to fraud? Ker HC explains whether marriage can be declared null & void

[Ajitha v. Harshan, Mat. Appeal No. 734 of 2012, decided on 25-09-2020]

 Transfer Petitions related to Matrimonial Disputes

While considering transfer petitions related to matrimonial disputes, the convenience of wife is to be preferred over the convenience of husband; Ker HC reiterates

[Kavitha v. Gopakumar, 2020 SCC OnLine Ker 6098, decided on 30-11-2020]


Madras High Court

Customary Divorce

Can plea of customary divorce be considered as a valid defence while departmental proceeding for bigamy is initiated? Madras HC considers scope of defence under Service Rules

[Sudalaimai v. Deputy Inspector General of Police, WP (MD) No. 17504 of 2014, decided on 09-09-2020]

 Illegitimate Child [Maintenance]

Is an illegitimate child entitled to maintenance under S. 125 CrPC? Madras HC reiterates legal position

[Pachaimuthu v. Minor Vishanthini, 2020 SCC OnLine Mad 2677, decided on 01-10-2020]

Limitation Period for Domestic Violence Complaints

Limitation provided under CrPC is applicable to complaints under Domestic Violence Act: Madras HC rejects complaint filed after lapse of 1 yr 10 months

[N. Prasad v. Harithalakshmi, 2020 SCC OnLine Mad 1767, decided on 20-07-2020]

 Void Marriage

What is the essential condition for validity of any marriage? Detailed Report highlighting legality of marriage of a girl below 18 years of age

[Prakash v. State, Crl. A. No. 334 of 2014, decided on 30-11-2020]


Orissa High Court

Rights of a “lady” in Same-sex Couple Relationship

Same-sex couple have a right to live together outside wedlock; Rights of a woman enshrined in Protection of Women from Domestic Violence Act, 2005 to apply on the “lady” in the relationship

[Chinmayee Jena v. State of Odisha, 2020 SCC OnLine Ori 602, decided on 24-08-2020]


Punjab & Haryana High Court

Sapinda Prohibition

Whether partners falling in sapinda prohibition under HMA can stay in a live-in relationship? Parties argue while hearing in anticipatory bail

[Akhilesh v. State of Punjab,  2020 SCC OnLine P&H 2058, decided on 19-11-2020]

Section 498-A IPC, a weapon?

Disgruntled wives use provisions of S. 498-A IPC as a weapon rather than shield: P&H HC

[Amarjit Kaur v. Jaswinder Kaur, 2020 SCC OnLine P&H 577, decided on 15-05-2020]

 Voidable Marriage

In case a marriage is solemnized in violation of age restriction, marriage is only voidable

[Deepak Kumar v. State of Haryana, 2020 SCC OnLine P&H 759 , decided on 15-06-2020]


Rajasthan High Court

Theory of Homicidal Death

Allegation of woman set ablaze in view of dowry demand dismissed; Prosecution theory of homicidal death sheer exaggeration; finds Raj HC

[Gopal v. State of Rajasthan, DB Criminal Appeal No. 799 of 2014, decided on 06-08-2020]


 Telangana High Court

Harassment or Cruelty

For invoking S. 304-B IPC, harassment or cruelty caused to a woman should have happened “soon before her death”

[Surender Singh v. State of A.P., 2020 SCC OnLine TS 874, decided on 06-07-2020]


Tripura High Court

Dissolution of Marriage of ST Couple

Will Hindu Marriage Act have application on a couple belonging to Scheduled Tribe notified under the Constitution for purpose of dissolution of marriage? Tripura HC explains

[Rupa Debbarma v. Tapash Debbarma, 2020 SCC OnLine Tri 425, decided on 09-09-2020]

Irretrievable Breakdown of Marriage

What amounts to irretrievable breakdown of marriage? Tripura HC discusses in a case where the couple lived apart for 13 continuous years

[Aparna Dey v. Alok Dey, 2020 SCC OnLine Tri 411, decided on 09-09-2020]

Lived like a Wife [Maintenance]

“Woman who lived like wife, cannot be deprived of maintenance”: Tripura HC grants maintenance to woman who “lived like wife” for 10 yrs

[Sri Bibhuti Ranjan Das v. Gouri Das, 2020 SCC OnLine Tri 280, decided on 07-07-2020]


Uttaranchal High Court

Medical Examination of Wife in Divorce Proceedings

Wife not eligible for medical examination of whether she can conceive or not during Divorce proceedings; Utt HC allows appeal

[Rashmi Gupta v. YogeshBabu, 2020 SCC OnLineUtt 339, decided on 01-07-2020]

 Mental Cruelty

Mental cruelty is no less than physical cruelty, wife causing mental cruelty to husband valid ground for dissolution of marriage; Utt HC dismisses appeal

[Anita Gaur v. Rajesh Gaur, 2020 SCC OnLineUtt 503, decided on 24-08-2020]


Also Read:

2020 Wrap Up — Flashback of Stories on Consumer Cases

Case BriefsHigh Courts

Bombay High Court: Mangesh S. Patil, J., in the present application directed the husband to pay an amount of Rs 10,000 towards alimony pendente lite under Section 24 of the Hindu Marriage Act.

Petitioner-wife has impugned the order passed by the Family Court, Judge wherein her application was rejected in which she sought interim alimony under Section 24 of the Hindu Marriage Act, 1955 in a divorce proceeding filed by the respondent-husband under Section 13(i–a) of that Act.

Petitioner submitted that she was unable to maintain herself since the time she and her husband separated. She was even unable to work due to the psychological pressure and harassment meted out to her by the respondent.

As against this, the respondent is a Medical Officer earning around Rs 60,000 to Rs 65,000 salary. No-one is dependent on him and therefore, she claimed interim maintenance at the rate of Rs 15,000 per month and also claimed Rs 200 for rickshaw fare for attending the Court for each date and Rs 25,000 for engaging Advocate.

Analysis and Decision

Bench stated that as far as the right of a wife, who is capable of earning, to claim alimony is concerned, Supreme Court in the decision of Rajnesh v. Neha,2020 SCC OnLine SC 903, considered it in clause (c) of Part III under the head of ‘Criteria for determining the quantum of maintenance’.

Court in view of the above concluded that even if the petitioner in the matter in hand is a medical practitioner and was earning something for her livelihood, the same cannot be a ground to refuse alimony to her under Section 24 of the Hindu Marriage Act.

Quantum of Maintenance

Bench observed that though the petitioner had produced her Income tax Returns, respondent did not reciprocate the gesture. Supreme Court’s decision in Rajnesh v. Neha, 2020 SCC OnLine SC 903, laid down several guidelines requiring both the parties to make several disclosures in the form of affidavits inter alia touching the income aspect as well. Conspicuously, in that matter, the Supreme Court had directed the husband to produce Income Tax returns before passing the order for granting interim maintenance.

Consequently, without indulging into further discussion, Court held that the failure of the respondent to come with disclosure as to his own income and taking into consideration all the aforementioned facts and circumstances and bearing in mind the guidelines laid down by the Supreme Court in the case of Rajnesh v. Neha, 2020 SCC OnLine SC 903 and resorting to inevitable guesswork, it would be just and proper to award interim maintenance to the petitioner at the rate of Rs 10,000 per month.

Along with the above direction of interim maintenance respondent shall pay all the arrears up to date to her within 12 weeks from the date of this judgment.

In view of the above discussion, the petition was partly allowed. [Arpana Vijay Manore v. Dr Vijay Tukaram Manore, 2020 SCC OnLine Bom 3925, decided on 09-12-2020]


Advocates who appeared for the matter:

B.R. Warma, Advocate holding for Shrirang B. Varma, Advocate for the petitioner

A.M. Gholap, Advocate for the respondent

Case BriefsHigh Courts

Madras High Court: A Division Bench of M. Sathyanarayanan and P. Rajamanickam, JJ., addressed an appeal with regard to seeking interim maintenance when permanent maintenance was already granted.

Petitioners have filed the present appeal challenging the Family Court’s Order.

Husband sought divorce against the first appellant(wife) on the ground of cruelty.

During the pendency of the above petition, appellants filed an application under Section 7(1) of the Family Courts Act read with Section 25 of the Hindu Marriage Act, 1955 and Sections 20 and 26 of the Protection of Women from Domestic Violence Act, 2005 to direct the husband to pay a sum of Rs 10,000 to appellant 1 and Rs 5,000 to appellant 2 towards monthly maintenance.

Another application under Section 24 of the Hindu Marriage Act, 1055 read with Sections 20 and 26 of the Protection of Women from Domestic Violence Act, 2005 to direct the respondent to pay a sum of Rs 7,500 to appellant 1 and Rs 5, 000, was also filed.

Counsel for the appellants, M.P. Senthil and Counsel S. Jeyavel, for the respondent.

Issues to be considered:

  • Whether the petitioners are precluded from seeking interim maintenance by invoking the provisions of Section 24 of the Hindu Marriage Act r/w Sections 20 and 26 of the Protection of Women from Domestic Violence Act on the ground that they already got an order for payment of maintenance in D.V proceedings?

Analysis & Decision

Bench referred to Section 25 of the Hindu Marriage Act, 1955, which is in regard to the permanent Alimony and Maintenance.

Section 25(1) of HMA empowers the Court, while passing any decree to consider the status of the parties and whether any arrangement needs to be made in favour of the wife or the husband and by way of permanent alimony, an order granting maintenance can also be passed by the Court.

“…at any time, subsequent to the passing of decree also, the Court can order for granting maintenance on application made to it by either wife or the husband.”

Bench noted that the appellants cannot ask for interim relief, when permanent relief has already been granted to them.

In view of the above, court relied on the decision of Rakesh Malhotra v. Krishna Malhotra, 2020 SCC OnLine SC 239 wherein the following was dealt with:

After grant of permanent alimony under Section 25 of the 1955 Act, prayer made by wife before Magistrate under Section 125 of Code for maintenance over and above what has been granted by Court under Section 25 of Act. Impugned order allowing prayer was set aside with direction that application preferred under Section 125 of Code shall be treated and considered as one preferred under Section 25(2) of Act.

What the appellants should have done in the present matter?

Since, the appellants had already received maintenance in the DV proceedings under Section 20 of the DV Act which is permanent in nature, yet if due to a change in the circumstances the said order required modification or alteration, they can approach the same Court seeking the relief by invoking Section 25(2) of the DV Act or the Family Court can also be approached to exercise the power under Section 25(1) of the HMA.

But the resort of filing another application before another forum that too in the nature of interim relief should not be adopted.

Section 26 of the DV Act shows that the aggrieved person may seek any relief under Sections 18 to 22 of DV Act in any legal proceedings before a Civil Court/Family Court or Criminal Court as additional reliefs.

In the present case, the petitioner had already received an order in the petition properly filed under Section 12 of the DV Act before the Additional Mahila Court, Tiruchirappalli and that being so, they were not entitled to file a petition before the Family Court by invoking the provision under Section 26(1) of the DV Act, seeking interim relief.

Therefore, in the High Court’s opinion, the  Family Court Judge had rightly dismissed the application. [Gomathi v. Sacraties,  2020 SCC OnLine Mad 2754, decided on 15-09-2020]

Case BriefsHigh Courts

Jharkhand High Court: Shree Chandrashekhar, J., addressed an issue with regard to maintenance under Section 125 of the Code of Criminal Procedure Code.

In the present revision petition, maintenance order under Section 125 of the Code of Criminal Procedure has been challenged.

Petitioner-Husband’s wife stated that her husband was irresponsible towards the conjugal relationship and neglected to maintain her. The matrimonial suit which was instituted by the husband seeking a divorce decree was disposed of on a compromise between the parties.

Petitioner’s counsel, Sanjay Prasad contended that the above-stated matrimonial suit was decreed “as per terms of the compromise” under which the wife had relinquished all her claims against the petitioner, hence petitioner’s wife was not entitled to maintenance under Section 125 of CrPC.

In the Supreme Court decision of Nagendrappa Natikar v. Neelamma, (2014) 14 SCC 452, Court dealt with the issue of whether a wife who has agreed for permanent alimony and given up future claim for maintenance is entitled to maintenance under Section 18 of the Hindu Adoption and Maintenance Act, 1956 after the divorce?

To the above, the Supreme Court responded that

“The proceeding under Section 125 CrPC is summary in nature and intended to provide a speedy remedy to the wife and any order passed under Section 125 CrPC by compromise or otherwise cannot foreclose the remedy available to a wife under Section 18(2) of the Act.”

In the present matter, Family Court Judge had observed that permanent alimony or maintenance was not given by the petitioner and the wife was unable to maintain herself. Hence, the Court awarded Rs 5000 monthly maintenance to the wife.

Object of Section 125 CrPC is to ensure that a wife, minor children or helpless parents do not suffer in penury.

High Court declined to interfere in the present matter keeping in mind the limitation under revisional jurisdiction and therefore dismissed the criminal revision.[Umesh Prasad Mahto v. Puspa Devi, 2020 SCC OnLine Jhar 645, decided on 06-07-2020]

Case BriefsHigh Courts

Calcutta High Court: Biswajit Basu, J. dismissed a revision application of the filed by a lady seeking alimony pendente lite.

The husband/respondent and the wife herein had filed a matrimonial suit seeking dissolution of their marriage by a decree of divorce, inter alia, on the grounds of cruelty. In the said suit, the wife had filed an application before the learned trial judge under Section 36 of the Special Marriage Act, 1954 praying alimony pendente lite at the rate of Rs 50,000 per month. The wife alleged that the husband is working in a reputed organization in the USA and was earning around Rs 75,00,000 per annum. Thus, she was entitled to maintenance proportionate to the income of the husband. However, after assessing her salary certificates for December 2018, January 2019 and March 2019, the learned judge opined that the present income of the wife is not less than Rs 74000 being sufficient for her support particularly when she herself assessed her requirement at Rs 50,000 in the application for alimony pendente lite.  And as Section 36 provides for temporary financial support pending any action under Chapter V or VI of the said Act “to the wife who has no independent income sufficient to maintain herself”, refused the prayer of the wife for alimony pendente lite.

The High Court dismissed the case, holding the decision of the learned trial Judge as absolutely justified.[Somdatta Chatterjee nee Raychaudhari v. Anindya Chatterjee, 2019 SCC OnLine Cal 1627, decided on 11-06-2019]

Case BriefsHigh Courts

Gauhati High Court: A Bench of A.S. Bopanna, CJ and Sanjay Kumar Medhi, J. dismissed an appeal filed by the appellant-husband against family court’s order granting alimony of Rs 2.5 lakhs to the respondent-wife.

Undisputed facts of the case are that the parties were formerly married to each other. Some marital disputes arose and the husband filed a petition seeking divorce which was granted by the family court. Subsequent to the divorce decree, the wife filed a petition under Section 25 of the Hindu Marriage Act, 1955 seeking permanent alimony of Rs 15 lakhs. Partly allowing the wife’s application, the family court awarded her alimony of Rs 2.5 lakhs. Aggrieved thereby, the husband filed the present appeal.

Dipika Kalita and Rumi Kalita, Advocates for the husband told the Court that during the pendency of the husband’s divorce petition, the parties entered into an agreement whereby the wife conceded to the prayer for divorce. Further, she also agreed that there would be no claim between the parties against each other. It was contended that the family court’s order was not justified.

Regarding the alleged agreement, the family court observed and the High Court noted that what was submitted in the divorce proceedings was a photocopy of the said agreement. The family court took note of the same and concluded that it was not enforceable. The High Court observed, “the law is well settled that the maintenance or the alimony to be granted is to enable the party who seeks the same subsequent to the dissolution of the marriage to maintain herself. At that stage, what would be relevant is as to whether the party seeking for such maintenance or alimony is able to maintain herself.” As such, the High Court was of the opinion that the family court rightly held that the wife was entitled to receive alimony. Also, no error was found with the quantum of alimony so granted. Holding it to be devoid of merits, the Court dismissed the appeal. [Utpal Das v. Rinki Sarkar, 2019 SCC OnLine Gau 1048, dated 08-03-2019]

Case BriefsHigh Courts

Gauhati High Court: Rumi Kumari Phukan, J., dismissed a revision petition filed by a husband against the order of the family court whereby the monthly amount payable by him towards the maintenance of his son was increased from Rs 2,000 to Rs 5,000.

A petition between the parties was disposed of by the family court whereby the husband was directed to pay monthly maintenance of Rs 2,500 to his wife and Rs 2,000 to their minor son. Subsequently, the parties got divorced under Section 13 of the Hindu Marriage Act, 1955. The husband paid a permanent alimony of Rs 5 lakhs to the wife. After the divorce, the wife filed a petition under Section 127 CrPC for enhancement of maintenance allowance to the minor son which was allowed by the family court in the terms mentioned above. Aggrieved thereby, the husband filed the present petition.

K.M. Haloi, B. Das and R. Sarkar, Advocates for the husband submitted that the enhancement of 300% was on a higher side and he had other liabilities to discharge. Per contra, K. Bhattacharjee, S. Das, J.C. Barman, D. Banerjee and S. Dey, Advocates appearing for the wife contended that the objection raised by the husband was not maintainable.

After taking the husband’s salary into consideration, the High Court was of the view that the enhancement of the maintenance by the court below did not require interference. The observed, “in the context of liability, the maintenance always carries the meaning that it should be adequate to the needs of a person and according to the status and income of the person concerned. The child of the petitioner who was enrolled in an English Medium School cannot be stopped to carry on such education by showing inability by his parents. It is bounded duty of a father to upbringing the child in a befitting manner without hindering his mental health as well as physical one. If the father denies such required amount, it will be nothing but denial of such mandatory requirement of a child for proper upbringing.” In such view of the matter, the revision petition was dismissed and the husband was directed to pay Rs 5,000 per month maintenance for the minor son. [Rupak Chowdhury v. State of Assam, 2019 SCC OnLine Gau 933, dated 22-01-2019]

Case BriefsHigh Courts

Calcutta High Court: A Single Judge Bench comprising of Sabyasachi Bhattacharya, J. allowed a challenge to the order of Additional District Judge for execution of an order passed under Section 24 of the Hindu Marriage Act, 1955.

The facts of the case are such that the Additional District Judge, while taking up an execution case in connection with an alimony order passed under the Hindu Marriage Act, suffered an identity crisis and acted as a Magistrate to invoke provisions of Section 125(3) CrPC and allied provisions to issue a distress warrant against the husband. The Collector was directed to realise the maintenance allowance as arrears of land revenue. The husband assailed the order as sans jurisdiction.

The High Court, at the outset, observed that it is unheard of that an order passed under Section 24 HMA would be executed by taking resort to the provisions of CrPC. In view of the Court, this was a case the execution application was filed under the correct provisions of law, but the Additional District Judge consciously resorted to powers which have no nexus with the proceedings under consideration; the powers that are conferred on a Magistrate and not on an Additional District Judge. As such, it was held that the order impugned was devoid of inherent jurisdiction and could not stand a moment’s scrutiny. Accordingly, the order impugned was set aside. The Additional District Judge was directed to dispose of the matter in accordance with appropriate provisions of law. [Taraknath Mukherjee v. Sandhya Mukherjee, 2018 SCC OnLine Cal 6154, dated 07-09-2018]

Case BriefsHigh Courts

Calcutta High Court: A Division Bench comprising of I.P. Mukerji and Amrita Sinha, JJ., allowed an appeal filed by the husband against the order of District Judge who directed him to pay permanent alimony of Rs 14 lakhs to the respondent wife.

Marriage between the parties to the appeal was dissolved by a decree passed by a District Judge in a suit filed by the husband under Section 13 of the Hindu Marriage Act, 1955. The suit was allowed against the wife on grounds of adultery and desertion. It was proved that the wife was in an adulterous relationship with a junior colleague of the husband. The wife filed an application for permanent alimony under Section 25, which was allowed by the District Judge and the order was passed as mentioned above. Aggrieved by the said order, the husband filed the present appeal.

The High Court perused Section 25 and found that grant of permanent alimony is subject to conditions. If at the time of deciding an application under the section, the wife is unchaste or has remarried, then the court may deny to grant the application. In the present case, the Court found that the wife was living in adultery which is unchaste conduct. Such conduct of the wife disentitled her from receiving any amount A permanent alimony and maintenance under Section 25. However, the husband was directed to pay 5 lakhs against maintenance of their son. The appeal was, thus, disposed of in above terms. [Ashutosh Bandhopadhyay v. Mukta Bandhopadhyay,2018 SCC OnLine Cal 5100, dated 31-07-2018]

Case BriefsSupreme Court

Supreme Court: A bench of N.V. Ramana and S. Abdul Nazeer JJ., modified the order of the High Court of Bombay in a divorce petition filed seeking for the modification of the maintenance and alimony amount.

The facts of the case state that the appellant (wife) had filed a petition under Section 27(1)(d) of the Special Marriage Act, 1954 before the Family Court in Mumbai seeking permanent alimony of Rs 30,00,00,000/- and interim maintenance of Rs 3,50,000/- for herself along with Rs 2,50,000/- for her minor daughter. Though, the Family Court had partly allowed the appellant’s application for interim maintenance. On obtaining the final order of divorce from the family Court and being dissatisfied with the same, the parties preferred an appeal to the High Court. Further, the appellant being aggrieved of the order of the High Court approached the Supreme Court seeking relief.

Therefore, the Supreme Court on considering the facts and orders passed by the High Court and Family court observed that considering the merits of the order of the High Court it did not require interference. In order to balance the interests of the parties, the Supreme Court modified the High Court’s order by allowing the withdrawal of Rs 2 Crores by the wife during intra-appeal as an interim measure. [Udita Nabha v. Ranjeet Nabha,2018 SCC OnLine SC 695, dated 16-07-2018]

Case BriefsSupreme Court

Supreme Court: In the case where the wife made reckless, defamatory and false accusations against her husband, his family members and colleagues, thereby lowering his reputation in the eyes of his peers, the Court held that mere filing of complaints is not cruelty, if there are justifiable reasons to file the complaints. Merely because no action is taken on the complaint or after trial the accused is acquitted may not be a ground to treat such accusations of the wife as cruelty within the meaning of the Hindu Marriage Act 1955. However, if it is found that the allegations are patently false, then there can be no manner of doubt that the said conduct of a spouse levelling false accusations against the other spouse would be an act of cruelty.

Considering the fact that later, the wife had filed another complaint alleging that her husband along with some other persons had trespassed into her house and assaulted her and that the police found, on investigation, that not only was the complaint false but also the injuries were self-inflicted by the wife, the Court held that though the acts of the wife in filing false complaints against the husband amounts to cruelty, the Court is, however, not oblivious to the requirements of the wife to have a decent house where she can live and since, her son and daughter-in-law may not continue to live with her forever, therefore, some permanent arrangement has to be made for her alimony and residence. As per the facts of the case, the wife continues to live in the house which belongs to the mother of the husband whereas the husband lives along with his parents in a separate house and the son and daughter-in-law of the parties live with the wife. The son is working with the husband.

The Bench of A.K. Goel and Deepak Gupta, JJ, hence, directed the husband to pay to the wife a sum of Rs. 50,00,000 as one time permanent alimony within 3 months and she will not claim any further amount at any later stage. The Court also directed that the wife shall continue to live in the house which belongs to the mother of the husband till the husband provides her a flat of similar size in a similar locality. For this purpose, the husband is directed to ensure that a flat of the value up to Rs. 1,00,00,000 be transferred in the name of his wife. [Raj Talreja v. Kavita Talreja, 2017 SCC OnLine SC 462, decided on 24.04.2017]